Tiger—Army's Armed Reconnaissance Helicopter - ...

Copy and paste this link to your website, so they can see this document directly without any plugins.


Keywords

Defence, Tiger, that, ANAO, Helicopter, Reconnaissance, Armed, with, contract, Report, aircraft, sustainment, Airbus, capability, cost, Capability, Support, 2016–17, Tiger—Army’s, Operational, Defence’s, No.11, Through-Life, fleet, acquisition, which, from, this, support, Final

Transcript

The Auditor-General
ANAO Report No.11 2016–17
Performance Audit
Tiger—Army’s Armed Reconnaissance Helicopter
Department of Defence
Australian National Audit Office
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
2
© Commonwealth of Australia 2016
ISSN 1036–7632 (Print)
ISSN 2203–0352 (Online)
ISBN 978-1-76033-167-2 (Print)
ISBN 978-1-76033-168-9 (Online)
Except for the content in this document supplied by third parties, the Australian National
Audit Office logo, the Commonwealth Coat of Arms, and any material protected by a trade
mark, this document is licensed by the Australian National Audit Office for use under the
terms of a Creative Commons Attribution-NonCommercial-NoDerivatives 3.0 Australia licence.
To view a copy of this licence, visit
http://creativecommons.org/licenses/by-nc-nd/3.0/au/.
You are free to copy and communicate the document in its current form for non-commercial
purposes, as long as you attribute the document to the Australian National Audit Office and
abide by the other licence terms. You may not alter or adapt the work in any way.
Permission to use material for which the copyright is owned by a third party must be sought
from the relevant copyright owner. As far as practicable, such material will be clearly labelled.
For terms of use of the Commonwealth Coat of Arms, visit the It’s an Honour website at
http://www.itsanhonour.gov.au/.
Requests and inquiries concerning reproduction and rights should be addressed to:
Senior Executive Director
Corporate Management Branch
Australian National Audit Office
19 National Circuit
BARTON ACT 2600
Or via email:
communication@anao.gov.au.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
3
Canberra ACT
1 September 2016
Dear President and Speaker
The Australian National Audit Office has undertaken an independent performance audit
in the Department of Defence titled Tiger—Army’s Armed Reconnaissance Helicopter.
The audit was conducted in accordance with the authority contained in the
Auditor-General Act 1997. I present the report of this audit to the Parliament.
Following its presentation and receipt, the report will be placed on the Australian
National Audit Office’s website—http://www.anao.gov.au.
Yours sincerely
Grant Hehir
Auditor-General
The Honourable the President of the Senate
The Honourable the Speaker of the House of Representatives
Parliament House
Canberra ACT
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
4
AUDITING FOR AUSTRALIA
The Auditor-General is head of the
Australian National Audit Office
(ANAO). The ANAO assists the
Auditor-General to carry out his
duties under the Auditor-General
Act 1997 to undertake
performance audits, financial
statement audits and assurance
reviews of Commonwealth public
sector bodies and to provide
independent reports and advice
for the Parliament, the Australian
Government and the community.
The aim is to improve
Commonwealth public sector
administration and accountability.
For further information contact:
Australian National Audit Office
GPO Box 707
Canberra ACT 2601
Phone: (02) 6203 7300
Fax: (02) 6203 7777
Email: ag1@anao.gov.au
ANAO audit reports and
information about the ANAO are
available on our website:
http://www.anao.gov.au
Audit Team
Alex Wilkinson
Jed Andrews
Jay Stoker
Dr Tom Clarke
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
5
Contents
Summary and recommendations .................................................................................................................... 7
Background ............................................................................................................................................... 7
Conclusion ................................................................................................................................................. 8
Supporting findings .................................................................................................................................... 8
Recommendations ................................................................................................................................... 10
Summary of Defence’s response ............................................................................................................ 11
Summary of Airbus Group Australia Pacific’s response to an extract of the proposed audit report ....... 11
Audit Findings ............................................................................................................................................. 13
1. Background ............................................................................................................................................. 15
Introduction .............................................................................................................................................. 15
Audits and external reviews of the Tiger ................................................................................................. 17
Audit approach ........................................................................................................................................ 18
2. Status of the Tiger Fleet .......................................................................................................................... 20
Did the acquisition progress to expectations in terms of budget and scheduled key milestones? ......... 21
What level of capability has the Tiger achieved? .................................................................................... 25
3. Sustaining the Tiger Fleet ....................................................................................................................... 34
Were the through-life support arrangements for the Tiger fleet well designed to support the
achievement of Defence’s sustainment requirements? ..................................................................... 36
Has Tiger’s sustainment performance met Defence’s requirements? .................................................... 39
Are sustainment costs within budget? ..................................................................................................... 45
Has Defence identified key lessons from the Tiger through-life support arrangements? ....................... 48
4. Future of the Armed Reconnaissance Helicopter capability ................................................................... 50
Are plans in place to achieve and maintain the defined capability? ........................................................ 50
Appendix 1 Defence’s response to the proposed audit report ............................................................... 59
Appendix 2 Airbus Group Australia Pacific’s response to the proposed report ..................................... 60
Appendix 3 Recommendations of the ‘Project AIR87 Phase 2—Rotary Wing for Land Force
Project Lessons Learned Report’ ....................................................................................... 64
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
7
Summary and recommendations
Background
The Armed Reconnaissance Helicopter is an important combat capability for the 1.
Australian Army (Army). Its intended functions include: undertaking airmobile escort missions;
and providing support to covering force, helicopter attack, and recovery missions. After
releasing a Request for Tender in December 2000, the Department of Defence (Defence) signed
a contract with Eurocopter International Pacific (now Airbus Group Australia Pacific (Airbus)) in
December 2001 for:
• the acquisition of 22 of its ‘Tiger’ variant helicopters at an acquisition cost of $1.1 billion
(2001 price); and
• a Through-Life Support contract at a cost of $397 million (2001 price).
Government approval for the acquisition was on the basis that it was a low-risk off-the-2.
shelf platform. The ANAO conducted a performance audit of the Tiger acquisition in 2005–06,
and concluded that Tiger was more developmental than off-the-shelf and this heightened
exposure to schedule, cost and capability risks, both for the acquisition of the aircraft and its
sustainment.
Australia is one of four countries to operate the Tiger aircraft.1 The small size of the 3.
international fleet, currently 119 aircraft, creates a niche capability with the associated
challenges of sustaining the aircraft within a limited supply-chain.2
Audit objective and criteria
The objective of the audit was to examine Defence’s progress since 20073 in introducing 4.
into service a fully capable Tiger fleet and cost-effective sustainment arrangements.
To form a conclusion against the audit objective, the ANAO adopted the following 5.
high-level audit criteria:
• the acquisition met Government expectations relating to cost, schedule and capability;
• the acquisition is providing value-for-money to the Australian Government in respect to:
cost of sustainment, rate of effort, and capability;
• Defence implemented appropriate contractual remedies, or alternate remediation, for
any under-performance by the contractor(s); and
• Defence appropriately informed Government of the status of the Tiger fleet.
1 Other countries operating the Tiger are France, Germany and Spain.
2 In contrast, the Army operates 35 Black Hawk helicopters from a total world fleet of some 2500 aircraft
operated by 25 countries.
3 The ANAO reported on the Tiger program in May 2006, in ANAO Report No.36 2005–2006 Management of
the Tiger Armed Reconnaissance Helicopter Project—AIR 87. This audit covers the period since 2007.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
8
Conclusion
The Tiger helicopter fleet has not yet delivered the original capability expected by the 6.
Australian Government, and continues to experience higher than expected sustainment costs
and lower than expected aircraft availability.
• The Chief of Army declared Final Operational Capability for the Tiger on 14 April 2016,
allowing the helicopter to be operationally employed. The declaration was seven years
later than planned, and was accompanied by nine operational caveats.
• As at April 2016, the Tiger also had 76 capability deficiencies relating to Army’s current
and future operational requirements, 60 of which were deemed by Defence to be
critical. Other key limitations relate to shipborne operations, pilot flying hours,
interoperability and communications, airworthiness, and the roof-mounted sight.
• To date, sustainment costs have exceeded the original contract value. The 15 year
(2004–2019) sustainment contract provided for expenditure of $571 million.4 That sum
was expended by June 2014, and expenditure as at June 2016 was $921 million.
• As at June 2016, the cost per flying hour for the Tiger fleet was $30 335, compared to a
target of $20 000. The long-term average was $39 472 per hour. Defence negotiated a
cost cap to control sustainment cost growth in 2014.
• On average only 3.5 aircraft of the operational fleet (16 aircraft) were serviceable at
10am on any given day in 2015, against a target of 12 aircraft.
Defence’s internal lessons learned review of the Tiger program concluded that the 7.
‘rushed’ nature of the initial Through-Life Support contract negotiations resulted in a flawed
outcome for the fleet’s sustainment, and that Defence was ineffective in enforcing its
contractual rights under the contract. These factors weakened Defence’s position in managing
the fleet’s sustainment arrangements.
The 2016 Defence White Paper allocated $500–$750 million to address the current 8.
capability requirements of the Tiger platform with a view to replacing the platform mid next
decade, at a cost of some $5–$6 billion. In effect, an upgrade is scheduled for consideration less
than 12 months after the Tiger achieved Final Operational Capability. Defence should conduct a
thorough analysis of the value-for-money of investing further in the Tiger, pending the
introduction of a replacement capability.
Supporting findings
Status of the Tiger fleet
The Acquisition contract for the Tiger system was completed in 2013. The Tiger 9.
acquisition had a budget of $2.03 billion. Defence spent $1.86 billion on the acquisition (capital
expenditure) and the remainder ($170 million) was unspent contingency.
The acquisition missed all but one of its scheduled key milestones. In April 2016, the 10.
Chief of Army declared that the Tiger had achieved the Final Operational Capability milestone,
4 June 2016 out-turned price.
Summary and recommendations
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
9
some seven years behind schedule. The developmental nature of the aircraft was a major factor
in the Tiger’s delayed introduction into service.
The declaration of Final Operational Capability allows the Tiger to be operationally 11.
employed in a land based ‘non-permissive environment’. The relevant documentation and
advice to the Defence Minister did not define the meaning of such an environment. The
declaration was made with nine caveats, including for the Electronic Warfare Self-Protection
System, Identification Friend or Foe System and Communication and Mission Planning System.
There were also several shortfalls between the initial Government approvals given in 2001 and
the capability realised when Final Operational Capability was declared in 2016. The shortfalls
related to aircraft availability, rate of effort and the threat environment in which the Tiger can
operate. Defence did not seek Government agreement to these shortfalls prior to declaring Final
Operational Capability, as required by Defence Instructions. The relevant Defence Instruction
provides that where a shortfall in capability occurs, Defence is to either:
• not accept the capability into operational service and determine a remediation plan; or
• accept the capability shortfall and, in cases where the shortfall ‘places the capability
outside the basis of the Government’s project approval’, notify and seek agreement by
the Government before the shortfall can be accepted by the Capability Manager.
When declaring Final Operational Capability, Defence should comply with the 12.
requirements of the Defence Instructions.
As at April 2016, the Tiger fleet had 76 deficiencies relating to Army’s current and future 13.
operational requirements, 60 of which were deemed by Defence to be critical and requiring
resolution. Other key limitations relate to shipborne operations, pilot numbers and flying hours,
interoperability and communications, airworthiness, rocket launchers and the roof-mounted sight.
The resolution of key deficiencies and lifting of operational caveats will require active 14.
management by Defence.
Sustaining the Tiger fleet
The through-life support arrangements for the Tiger fleet were not well designed. The 15.
Through-Life Support contract signed in 2001 by Defence with Airbus—the single sustainment
provider—provided limited recourse for Defence to address under-performance in Tiger’s
required availability and serviceability. In 2008 and 2014, Defence negotiated changes with
Airbus to improve the Through-Life Support contract. The 2008 contract renegotiation
introduced performance management arrangements, and nearly doubled the value of the
sustainment contract. The 2014 renegotiation further amended the performance management
arrangements, and changed the payment mechanism. Operating costs remain high, and aircraft
availability continues to fall short of target.
The Tiger fleet has consistently underperformed against its sustainment metrics and 16.
targets for availability and rate of effort. On average, only 3.5 aircraft, from an operational fleet
of 16 aircraft, were considered serviceable at 10am on any given day in 2015. Further, Defence
considers that the Tiger fleet is unlikely to exceed 74 per cent of its original target for rate of
effort. The revised mature target is 5300 flying hours per year as compared to the original target
of 7147 flying hours.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
10
Despite the Tiger fleet’s low rate of effort, by June 2014 sustainment costs for the Tiger 17.
had exceeded the original contract value, with five years still remaining. On a year-to-year basis,
sustainment costs have regularly exceeded Army’s annual allocated budget, in some years by as
much as 20 per cent. Between 2007 and 2016, sustainment costs exceeded Army’s annual
budget by some $54 million. As of July 2016 the cost per flying hour for the Tiger fleet was
$30 335, against a target of $20 000. The long-term average was $39 472 per hour.
In December 2014, Defence and Airbus agreed to new Through-Life Support contract 18.
arrangements that introduced a cap on the growth in the cost of sustainment arrangements.
The maximum total cost of the amended 15 year Through-Life Support contract is $1.32 billion,
more than double the initial contract amount of $571 million (June 2016 out-turned).
Defence developed a Lessons Learned Report on the Tiger acquisition in April 2015. The 19.
Report highlighted the ‘rushed’ nature of the initial Through-Life Support contract negotiations,
which resulted in a flawed outcome for the Tiger Fleet’s sustainment. The Report also identified
that Defence’s ineffectiveness in enforcing its contractual rights under the Through-Life Support
contract weakened its position in managing the Tiger fleet’s sustainment arrangements.
The Lessons Learned Report made five recommendations. The findings of the report and 20.
its recommendations should be communicated to all current and future sustainment managers
within Defence.
Future of the Armed Reconnaissance Helicopter capability
The Tiger has a number of systems which are obsolete or are approaching obsolescence. 21.
Defence’s main program for addressing the future of the Tiger is Project Land 9000 Armed
Reconnaissance Helicopter Capability Assurance Program. This Project was initiated in 2014, and
has not yet received Gate Zero approval. The final form of the Capability Assurance Program—
whether to upgrade or replace the Tiger—has not been finalised. Given the current state of the
aircraft, an upgrade of the Tiger would also have to remediate the aircraft’s known deficiencies.
Recommendations
Recommendation
No.1
Paragraph 3.43
That Defence implements arrangements to capture in its policies and
procedures the lessons learned from project reviews of contract and
sustainment arrangements. Key lessons learned should also be
disseminated to relevant internal stakeholders.
Defence’s response: Agreed.
Recommendation
No.2
Paragraph 4.22
That Defence assesses, and advises Government, on the value-formoney in investing further in the Tiger aircraft fleet for only a short
period of improved performance, against other alternatives. This
assessment should take into account the associated technical risks of
upgrading an aircraft which has not fully delivered the level of capability
originally expected by Government.
Defence’s response: Agreed.
Summary and recommendations
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
11
Summary of Defence’s response
Defence acknowledges the findings contained in the audit report on Tiger – Army’s Armed
Reconnaissance Helicopter and agrees with the two recommendations.
Army operates a sound capability. Whilst the capability continues to be expensive to operate, the
cost control around the Australian Tiger sustainment system is highly regarded by other user
nations (France, Germany and Spain). Further, it is improving along the road map that was set for it
by CEO DMO, and committed to by CEO Airbus Helicopters, during 2014.
Defence has made significant progress on improving its current and future through-life-support
costs and rate of effort. Furthermore, lessons learnt from the Tiger acquisition project and
sustainment are continuously applied as Army and Capability Acquisition and Sustainment Group
deliver the capability.
Defence acknowledges the deficiencies of the Tiger capability highlighted in the report as areas
which will require upgrade or modification to remain relevant within the future battlespace.
Defence will assess best value for money and the most effective capability for both the Tiger, and
the Tiger Replacement, going forward.
Summary of Airbus Group Australia Pacific’s response to an extract of
the proposed audit report
The Extract summarises the introduction into service of the Tiger ARH since 2007 and notes the
considerable delays experienced in achieving the key Project milestones. Airbus Group Australia
Pacific acknowledges these delays and generally agrees with the suggestion that this was largely
caused by the maturity of the Tiger during the acquisition phase. Airbus Group Australia Pacific, its
parent company Airbus Helicopters and all of the industry partners that support the Tiger have
been strongly engaged over the past two years in a dedicated program to resolve all known issues
with the support and operation of the aircraft. Under a dedicated Task Force the support
arrangements have been extensively remediated with the result that support issues do not
significantly contribute to lack of available aircraft.
The efforts to improve the levels of serviceable aircraft now focuses on the reliability of some
systems, maintenance burden reduction and optimisation of support arrangements in the
Operational Unit. Both CASG and Army have expressed their support for the initiatives and
acknowledge the improvement plans which are in place. It is the view of Airbus Group Australia
Pacific that the Extract does not provide a balanced view of the Tiger ARH as it does not appreciate
the significant improvements which have been made in the past two years nor the positive trend
of all support key performance indicators.5
5 ANAO comment – a number of specific issues were raised in Airbus Group Australia Pacific’s comments on an
extract of this report. See Appendix 2 for ANAO commentary on key issues.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
13
Audit Findings
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
15
1. Background
Introduction
The Armed Reconnaissance Helicopter is an important combat capability for the Australian 1.1
Army (Army). Its intended functions include: undertaking airmobile escort missions; and providing
support to covering force, helicopter attack, and recovery missions.6 The acquisition process for the
Armed Reconnaissance Helicopter was initiated in February 1994, to replace Army’s then existing
reconnaissance and fire support capability, the Bell 206B-1 and Iroquois UH1-H helicopters. After
releasing a Request for Tender in December 2000, the Department of Defence (Defence) signed a
contract with Eurocopter International Pacific (now Airbus Group Australia Pacific (Airbus)) in
December 2001 for:
• the acquisition of 22 of its ‘Tiger’ variant helicopters (Figure 1.1) at an acquisition cost of
$1.1 billion (2001 price); and
• a Through-Life Support contract at a cost of $397 million (2001 price).
Figure 1.1: Tiger—Army’s Armed Reconnaissance Helicopter
Source: Department of Defence.
Australia is one of four countries to operate the Tiger aircraft.7 The small size of the 1.2
international fleet, currently 119 aircraft, creates a niche capability with the associated challenges
of sustaining the aircraft within a limited supply-chain.8 The acquisition strategy for the Tiger
required the fleet to achieve Final Operational Capability during 2009. This milestone was not
achieved until April 2016, some 7 years behind schedule. The slippage in achieving capability
milestones is displayed in Figure 1.2.
6 The Tiger is intended to be operable in a range of threat level environments.
7 Other countries operating the Tiger are France, Germany and Spain.
8 In contrast, the Army operates 35 Black Hawk helicopters from a total world fleet of some 2500 aircraft
operated by 25 countries.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
16
Figure 1.2: Slippage to Tiger’s Acceptance into Operational Service capability
milestones
Note: Blue: Delay between original and achieved date.
Grey: Not yet achieved. Current delay between original and scheduled completion date.
Definition of Operational Milestones – IOR: Initial Operational Release, commencement of Test and Evaluation;
OC1: Operational Capability 1 Deployable Troop – Land (permissive); OC2: Operational Capability 2 Deployable
Squadron – Land (non-permissive); OC3: Operational Capability 3 Deployable Troop and Squadron – Land (nonpermissive); OC4: Operational Capability 4 Deployable Troop – Amphibious; OC5: Operational Capability 5
Deployable Squadron – Land; OC6: Deployable Squadron – Amphibious; FOC: Final Operational Capability
Deployable Regiment.9
Source: ANAO analysis of various Defence documents.
Australia’s Tiger fleet typically comprises: 1.3
• two operational squadrons of eight aircraft each, operated by Army’s 1 Aviation
Regiment in Darwin;
• one aircraft being rotated through Deeper Maintenance in support of 1 Aviation
Regiment; and
• five aircraft at the Army Aviation Training Centre in Oakey.
The typical distribution of Army’s Tiger fleet is displayed in Figure 1.3. 1.4
9 In 2013, the Army agreed to align the achievement of Tiger’s shipborne operations capability with the
introduction into service of the Navy’s Landing Helicopter Dock ships. As a result, Defence considered that the
achievement of shipborne operations capability would no longer be a prerequisite for the declaration of
Tiger’s Final Operational Capability, which was restricted to land based operations only.
40 31 61 78 92 84 94 82
0
10
20
30
40
50
60
70
80
90
100
IO
R
O
C
1
O
C
2
O
C
3
O
C
4
- A
m ph ib io us O
C
5
O
C
6
- A
m ph ib io us FO
C
D
el ay (m on th s) Capability Milestone
Background
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
17
Figure 1.3: Distribution of Army’s Tiger fleet (22 aircraft)
Darwin – 1 Aviation Regiment Oakey – Army Aviation
Training Centre
161 Squadron 162 Squadron
Instrumented aircraft *
17 aircraft 5 aircraft
Legend
Army has one instrumented aircraft which is permanently fitted with in-flight test instrumentation*
1 Aviation Regiment typically has one aircraft being rotated through Deeper Maintenance
Source: ANAO analysis of Defence documents.
Army did not deploy the Tiger during its prolonged engagements in Afghanistan and Iraq. 1.5
In the 2016 Defence White Paper, the Government indicated that it intends to commence a
program of ‘essential upgrades’ of the aircraft to ‘maintain the capability’s effectiveness’10, and
signalled that it plans to replace the current Tiger fleet in the middle of the next decade.
Audits and external reviews of the Tiger
The ANAO conducted a performance audit of the Tiger acquisition in 2005–06, and 1.6
concluded that the developmental nature of the Tiger had heightened exposure to schedule, cost
and capability risks, both for the acquisition of the aircraft and its sustainment. The lack of
operational experience in maintaining the Tiger in other defence forces meant that the original
cost estimates for through-life support of the aircraft were immature, and exposed Defence to
significant future budgetary risks.11
10 Department of Defence, Defence Integrated Investment Program, 2016, p. 114.
11 ANAO Report No.36 2005–2006 Management of the Tiger Armed Reconnaissance Helicopter Project—AIR 87,
p. 16.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
18
The Senate Foreign Affairs, Defence and Trade References Committee conducted an 1.7
inquiry in 2012 into Procurement procedures for Defence capital projects. In its Final Report, the
Committee reiterated the findings of the 2005–06 ANAO Report, and found that prior to contract,
Defence was aware of the significant risk and developmental nature of the Tiger aircraft, and had
made a ‘deliberate decision … not to advise the capability manager (and by extension it is
assumed government) of this information’.12 The Committee also emphasised the importance of
test and evaluation of platforms prior to acquisition and acceptance.13
The Tiger acquisition (Project AIR 87 Phase 2) has been included in all eight ANAO Major 1.8
Projects Reports since the first Report was released in 2007–08. In the most recent Major Projects
Report (2014–15), Defence identified three major project issues14:
• The Groundcrew Training Devices, delivered to the Acquisition contract specifications, no
longer meet Army’s necessary training outcomes.
• The Electronic Warfare [Self-Protection] System fitted to the [Tiger] is not performing to
specification during specific aircraft manoeuvres.15
• In Financial Year 2013–14 the estimated cost of sustaining the [Tiger] in exchange of
flying hours represents very poor return on investment for Army. Army requires
adjustment to the sustainment contract to ensure value for money.16
Audit approach
The objective of the audit was to examine Defence’s progress since 2007 in introducing 1.9
into service a fully capable Tiger fleet and cost-effective sustainment arrangements.
To form a conclusion against the audit objective, the ANAO adopted the following 1.10
high-level audit criteria:
• the acquisition met Government expectations relating to cost, schedule and capability;
• the acquisition is providing value-for-money to the Australian Government in respect to:
cost of sustainment, rate of effort, and capability;
• Defence implemented appropriate contractual remedies, or alternate remediation, for
any under-performance by the contractor(s); and
• Defence appropriately informed Government of the status of the Tiger fleet.
The scope of the audit included: progress made by Defence in introducing the Tiger into 1.11
service since a 2007 re-baselining of the acquisition and Through-Life Support contracts; the
current capability status of the fleet; and the cost and performance of the Tiger sustainment
arrangements.
12 Senate Foreign Affairs, Defence and Trade References Committee, Procurement procedures for Defence
capital projects, Final Report 2012, p. 20.
13 ibid., pp. 20–21.
14 ANAO Report No.16 2015–16, Major Projects Report 2014–15, p. 278.
15 Issues with the Electronic Warfare Self-Protection System are discussed in Chapter 2 of this audit report.
16 The Through-Life Support contract was renegotiated in December 2014. This is discussed in Chapter 3 of this
audit report.
Background
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
19
The audit method involved review of: 1.12
• Defence records relating to the introduction into service of the Tiger fleet;
• Defence assessments of the Tiger’s capability;
• data and documents relating to the sustainment of the Tiger fleet;
• contracts between Defence and Airbus; and
• Defence capability plans.
The ANAO also conducted site visits to the Army Aviation Training Centre at Oakey in 1.13
Queensland; and 1 Aviation Regiment17, Darwin, which operate the aircraft.
The audit was conducted in accordance with the ANAO auditing standards at a cost to the 1.14
ANAO of approximately $567 800.
17 Army arranges its operational units in a series of formations: a Regiment is one segment of a Brigade.
1 Aviation Regiment is the Armed Reconnaissance Helicopter segment of Army’s 16th Aviation Brigade. The
16th Aviation Brigade also includes the 5th and 6th Regiments, which operate Army’s Multi-Role, Chinook, Black
Hawk and Kiowa helicopters.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
20
2. Status of the Tiger Fleet
Areas examined
This Chapter examines:
• if the acquisition progressed to expectations in terms of budget and scheduled key
milestones; and
• the level of capability achieved by the Tiger.
Conclusion
The Tiger achieved Final Operational Capability in April 2016, some seven years later than
planned. The developmental nature of the Tiger was a major factor in the aircraft’s delayed
introduction into service, and was contrary to Defence’s expectations in 2001 that Tiger would
be an ‘off-the-shelf’ acquisition.
The Tiger acquisition had a budget of $2.03 billion as at 2015. Defence spent $1.86 billion on the
acquisition (capital expenditure) and the remaining $170 million was unspent contingency.
Defence finalised the Acquisition contract in May 2013, but when Final Operational Capability
was declared in April 2016, the Tiger had not delivered the original capability expected by
Government. As at April 2016, the Tiger fleet had 76 capability deficiencies relating to Army’s
current and future operational requirements, 60 of which were deemed by Defence to be
critical and requiring resolution.
Final Operational Capability was declared with nine caveats. Defence expects four of the
caveats to be resolved between 2016 and 2019. There were also several shortfalls between the
initial approvals in 2001 and the capability realised at Final Operational Capability in 2016.
Defence did not seek Government agreement to these shortfalls prior to declaring Final
Operational Capability, as required by Defence Instructions.
Areas for improvement
The resolution of key deficiencies and lifting of operational caveats will require active
management by Defence. When declaring Final Operational Capability, Defence should comply
with the requirements of the Defence Instructions relating to seeking agreement from
Government before accepting shortfalls in capability.
On 21 December 2001, the Commonwealth entered into two contracts with Airbus 2.1
(formerly Eurocopter International Pacific) for:
• the acquisition of an Armed Reconnaissance Helicopter capability; and
• the provision of 15 years’ through-life support for the capability.
The Acquisition contract included the delivery to Defence of: 22 Tiger Armed Reconnaissance 2.2
Helicopters (Tiger)18; a full flight and mission simulator; two Cockpit Procedures Trainer(s); ground
crew training devices; an Electronic Warfare Mission Support System; Ground Mission Equipment;
and supporting stores, facilities and ammunition.
18 The 22 helicopters were configured to meet the capability requirements for aerial reconnaissance and fire
support at the agreed Baseline Configuration 4 which was achieved, after a retrofit program, in 2012. This
included one instrumented aircraft which is permanently fitted with in-flight test instrumentation.
Status of the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
21
Prior to contract signature in December 2001, Defence had an Equipment Acquisition 2.3
Strategy to acquire an off-the-shelf Armed Reconnaissance Helicopter system to lower the risk of
schedule, cost and performance shortfalls. In October 2001, a team of Defence test pilots and
flight test engineers conducted a series of ground and flight tests on the Tiger. The results of these
tests were published in an Aircraft Research and Development Unit Preview Evaluation.19 The
Evaluation highlighted the developmental nature of the Tiger and the key schedule and technical
risks associated with its acquisition. Government approved and Defence proceeded with the
acquisition of the Tiger on the basis it was a low-risk off-the-shelf platform.
Did the acquisition progress to expectations in terms of budget and
scheduled key milestones?
The Acquisition contract for the Tiger system was completed in 2013. The Tiger acquisition had
a budget of $2.03 billion.a Defence spent $1.86 billion on the acquisition (capital expenditure)
and the remainder ($170 million) was unspent contingency.
The acquisition missed all but one of its scheduled key milestones. In April 2016, the Chief of
Army declared that the Tiger had achieved the Final Operational Capability milestone, some
seven years behind schedule. The developmental nature of the aircraft was a major factor in
the Tiger’s delayed introduction into service.
2015 price, adjusted for inflation. Note a:
Acquisition budget
The Tiger acquisition had a budget of $2.03 billion.20 Defence spent $1.86 billion on the 2.4
acquisition (capital expenditure) and the remainder ($170 million) was unspent contingency. 21
A breakdown of expenditure under the Acquisition contract is provided in Figure 2.1.
19 A Preview Evaluation involves a series of ground and flight assessments. In 2015, Defence instituted a policy
for the completion of preview test and evaluation prior to entering First Pass, a process analogous to the use
of Preview Evaluation.
20 2015 price, adjusted for inflation.
21 The project was approved in March 1999 with a budget of $1.58 billion (December 1999 prices). Since 2001,
the budget has increased by $418.2 million as a result of price index variation, and $121.5 million as a result
of exchange rate variations. The 2014–15 project budget was $2.03 billion.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
22
Figure 2.1: Acquisition expenditure, per financial year
Source: Department of Defence.
Delays to scheduled key milestones
As at April 2016, Project AIR 87 Phase 2 has been in progress for 171 months (14 years) 2.5
against an initial schedule of 78 months (6.5 years). The developmental nature of the aircraft
affected the project in a number of ways, including: late delivery of the aircraft by Airbus; ongoing
design issues; low aircraft reliability and sustainability; and reduced flying hours.
The Project appeared in Defence’s first Projects of Concern list22 in January 2008, and was 2.6
removed from the list in April 2008 after Defence classified the Project as ‘remediated’. A further
eight years passed before the declaration of Final Operational Capability (April 2016). During this
period Tiger was not put back onto the Projects of Concern list.23
A timeline of key project milestones and events is displayed in Figure 2.2. 2.7
22 The Projects of Concern list comprises projects experiencing significant commercial, technical, cost and/or
schedule difficulties. Projects on the list receive targeted senior management attention and are required to
report more regularly to the Government. Projects are removed from the list once the identified deficiencies
have been remediated.
23 Final Operational Capability was originally planned for 2009.
$1.21 $1.53
$121.68
$15.19
$285.02
$381.74
$261.58
$151.23
$90.72
$152.01
$174.67
$96.09
$80.2
$44.93
$6.56 $1.24 $.07
$
$50
$100
$150
$200
$250
$300
$350
$400
19
99
–0
0
20
00
–0
1
20
01
–0
2
20
02
–0
3
20
03
–0
4
20
04
–0
5
20
05
–0
6
20
06
–0
7
20
07
–0
8
20
08
–0
9
20
09
–1
0
20
10
–1
1
20
11
–1
2
20
12
–1
3
20
13
–1
4
20
14
–1
5
20
15
–1
6
Ex pe nd itu
re ($
m )
Fi gu re 2
.2
:
Ti m el in e of k ey p ro je ct m ile
st on es a nd e ve nt s D
ec em be r O
pe ra tio
na lly
C
ap ab le H
el ic op te r M
ile
st on e (2
7
m on th d el ay ) Ju
ne A
IR
8
7
P
ro je ct O
ffi
ce c lo se d M
ar ch Fi na l M
at er ie l R
el ea se (2
0
m on th d el ay )
S
ep te m be r In iti
al M
at er ie l R
el ea se (n o de la y) a nd In iti
al O
pe ra tio
na l R
el ea se (3
4
m on th d el ay )
D
ec em be r In -S
er vi ce D
at e an d th e fir
st tw o A
R
H
d el iv er ed 20
02
20
03
20
04
20
05
20
06
20
07
20
08
20
09
20
10
20
11
20
12
20
14
20
15
20
16
20
17
20
18
20
19
20
13
D
ec em be r 2
00
1
- M
ay 2
01
3
A
ct ua l A
cq ui si tio
n C
on tra
ct le ng th (6
8
m on th d el ay )
A
pr il Fi na l O
pe ra tio
na l C
ap ab ili
ty
L
an d, w ith
c av ea ts (8
2
m on th d el ay )
N
ov em be r 22
nd p ro du ct io n A
R
H
d el iv er ed (4
3
m on th d el ay )
Fe br ua ry Fu ll Fl ig ht a nd M
is si on S
im ul at or ; a
nd 2
C
oc kp it P
ro ce du re s Tr ai ne rs (6
0
m on th d el ay )
20
01
-
20
08
S
ch ed ul ed A
cq ui si tio
n C
on tra
ct le ng th Ju ne Ty pe A
cc ep ta nc e R
ev ie w S
pe ci al F
lig
ht P
er m it (8
m on th d el ay )
O
ct ob er A
us tra
lia
n M
ili
ta ry T
yp e C
er tif
ic at e (4
m on th d el ay )
A
pr il D
ee d of A
gr ee m en t a
nd R
em ov al fr om D
ef en ce ’s
P
ro je ct s of C
on ce rn Ju ly O
C
4

Tr oo p A
m ph ib io us (9
2
m on th d el ay )
Ju ly O
C
6

S
qu ad ro n A
m ph ib io us (9
4
m on th d el ay )
Th es e m ile
st on es h av e no t ye t b
ee n ac hi ev ed .
20
17
Fo re ca st A
R
H
up gr ad e G
at e Ze ro ap pr ov al $5
00
-$
75
0
m ill
io n N
ot es :
O
C
: O
pe ra tio
na l C
ap ab ili
ty .
R
ed li ne : t
im e el ap se d at th e tim
e of th e au di t. M
ile
st on es in b lu e w er e no t o
rig
in al m ile
st on es , t
he y w er e in tro
du ce d ov er th e lif
e of th e pr oj ec t. S
ou rc e: A
N
A
O
a na ly si s of D
ef en ce d oc um en ts .
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
24
ANAO Major Projects Report—Tiger acquisition
The Tiger acquisition project has been included in all eight ANAO Major Projects Reports 2.8
since the first Report was released in November 2008. Since Defence declared Final Materiel
Release in March 2014, the Capability Acquisition and Sustainment Group (formerly the Defence
Materiel Organisation) has not reached agreement within Defence to pursue the removal of the
project from the Major Projects Report. Removal would require consultation with the
Parliament’s Joint Committee of Public Accounts and Audit. In August 2014, Chief of Army wrote
to the General Manager Joint, Systems and Air, relating to the low risk rating applied to Project
AIR 87 Phase 2 by the then Defence Materiel Organisation, and its intention to seek to have the
Project removed from the Major Projects Report:
In relation to AIR87 Ph2 I have some deep concerns. I do not agree with your overall risk rating of
low. I assess that there is a high risk to achievement of [Final Operational Capability] by Jan 16,
particularly in relation to poor Rate of Effort generation and deficiencies in the Electronic
Warfare System. I note that these issues were also highlighted in Army's approval of [Final
Material Release] at ref B. Although challenges remain in several [Fundamental Inputs to
Capability] elements, [Defence Materiel Organisation] has a clear responsibility to resolve
challenges in these two areas. I request you reconsider the overall risk rating, after which I would
be happy to consider removal of this project from the Major Projects Report.
Project AIR 87 remained in the Major Projects Report, and in the most recent (2014–15) 2.9
Report, the continuing risks associated with rate of effort, Ground Crew Training Devices,
Electronic Warfare Self-Protection Systems, and cost of ownership are identified.24 The schedule
slippage experienced by the Tiger is also consistent with the Major Projects Report’s findings25
that Defence acquisition projects approved prior to 2005 present a greater risk to Defence in
achieving Final Operational Capability within the scheduled timeframe.26
24 ANAO Report No.16 2015–16, Major Projects Report 2014–15, pp. 277–8.
25 ibid., pp. 51–2.
26 In 2005, Defence introduced a series of reforms based on the Defence Procurement Review 2003 (the Kinnaird
Review) which concluded that Defence needed to further reform its acquisition management, and become
more business-like and outputs-focused. Key reforms adopted by Defence in response to the review included
the strengthening of the capability and assessment process prior to acquisition. See ANAO Audit Report No.6
2013–14, Capability Development Reform, for further discussion of the Kinnaird reforms.
Status of the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
25
What level of capability has the Tiger achieved?
The declaration of Final Operational Capability allows the Tiger to be operationally employed
in a land based ‘non-permissive environment’. The relevant documentation and advice to the
Defence Minister did not define the meaning of such an environment. The declaration was
made with nine caveats, including for the Electronic Warfare Self-Protection System,
Identification Friend or Foe System and Communication and Mission Planning System. There
were also several shortfalls between the initial Government approvals given in 2001 and the
capability realised when Final Operational Capability was declared in 2016. The shortfalls
related to aircraft availability, rate of effort and the threat environment in which the Tiger can
operate. Defence did not seek Government agreement to these shortfalls prior to declaring
Final Operational Capability, as required by Defence Instructions. The relevant Defence
Instruction provides that where a shortfall in capability occurs, Defence is to either:
• not accept the capability into operational service and determine a remediation plan; or
• accept the capability shortfall and, in cases where the shortfall ‘places the capability
outside the basis of the Government’s project approval’, notify and seek agreement by
the Government before the shortfall can be accepted by the Capability Manager.
When declaring Final Operational Capability, Defence should comply with the requirements of
the Defence Instructions.
As at April 2016, the Tiger fleet had 76 deficiencies relating to Army’s current and future
operational requirements, 60 of which were deemed by Defence to be critical and requiring
resolution. Other key limitations relate to shipborne operations, pilot numbers and flying
hours, interoperability and communications, airworthiness, rocket launchers and the roofmounted sight.
The resolution of key deficiencies and lifting of operational caveats will require active
management by Defence.
Final Operational Capability is declared when the designated Defence Capability Manager 2.10
considers that the capability to be delivered by a project is able to be operationally employed.27
On 14 April 2016, the Chief of Army declared Final Operational Capability for the Tiger. On the
recommendation of key advisors, the Chief of Army declared that:
Army can deploy an aviation battle group Headquarters based on Headquarters 1 Aviation
Regiment, simultaneously with a Tiger squadron for a single sustainment period reducing to an
on-going deployment of a troop in a land based non-permissive environment.
Final Operational Capability—caveats
The declaration of Tiger’s Final Operational Capability was accompanied by nine ‘caveats’.28 2.11
Table 2.1 summarises the caveats and their expected resolution.
27 Department of Defence, DI(G) OPS 45–2, Capability Acceptance into Operational Service, November 2012.
28 Defence has not formally defined the effect of caveats on the declaration of Final Operational Capability. In
May 2016, Defence described caveats to the ANAO as ‘alerts’ to operational decision makers about risks to be
taken into account when making decisions about the use of the Tiger in particular operational circumstances.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
26
Table 2.1: Caveats on Final Operational Capability
Caveat Description Expected resolution (as at
14 April 2016)
Electronic Warfare
Self-Protection
System
The system currently exhibits deficiencies. Airbus is currently developing an
engineering solution, with an
expected final delivery date of
December 2016.
Availability and rate
of effort
Tiger availability is likely to plateau at 50 per
cent availability (four from eight aircraft per
two squadrons). Tiger is currently expected
to fly 4500 hours during 2015–16 and is
unlikely to exceed 5400 hours in future years.
Defence’s Final Operational
Capability declaration stated that
‘industry and Defence must
continue to improve availability’.
Identification Friend
or Foe System
(Mode 4)
The system is experiencing technical and
integration issues.
June 2016.
Communication
and mission
planning
Limitations exist with voice and data
communication and the Ground Mission
Equipment mission planning suite.a
Ground Mission Equipment will
be replaced with a new Joint
Mission Planning System
commencing mid-2017. Radio
obsolescence expected to be
resolved by the end of 2019.
Missiles AGM-114M Hellfire missile is no longer
manufactured by the original Equipment
Manufacturer.
The next generation Hellfire
missile is not expected to be
released into service until
late 2017.
Ammunition Availability issues. Stocks procured.
Spare parts and
consumables
Supply constraints on breakdown spares and
consumables.
No resolution in the short to
medium term identified.
Class IX Fly Away
Kits
Each kit is designed to support a troop-level
deployment in a field environment for 14
days. Defence currently has limited stocks.
No current resolution identified.
Support Engineering capacity within Defence and
industry is constrained with the potential to
affect capability.
No current resolution identified.
See paragraphs 2.21–2.23. Note a:
Source: Department of Defence documentation.
Final Operational Capability—advising Government of shortfalls against initial
project approval
Typically, Final Operational Capability is declared when the equipment meets the capability 2.12
initially approved by Government.29 In the case of Tiger, there were several gaps between the
initial approvals in 2001 and the capability realised at Final Operational Capability in 2016. Table 2.2
illustrates the key shortfalls in respect of availability, rate of effort and threat environment. With
regard to availability for example, Defence now expects that eight aircraft will be available. The
29 Department of Defence, DI(G) OPS 45–2, Capability Acceptance into Operational Service, November 2012.
Status of the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
27
Government’s original expectation, based on Defence’s advice, was that 12 aircraft would be
available.30
Table 2.2: Shortfalls against initial project approval at Final Operational Capability
Initial approval Status at Final Operational Capability
Availability A minimum of six aircraft available
from the eight aircraft in each of
Army’s 161 and 162 squadrons
(see Figure 2.3 below).
Defence expected Tiger availability to
plateau at 50 per cent availability (four
aircraft available from the eight aircraft in
each of the two squadrons).
Rate of effort A mature rate of effort of 7147
hours per year.
Defence considered that it was unlikely
that Tiger would exceed 5400 hours in
future years.a
Threat environment Non-permissive, medium-high
threat environment.b
Non-permissive, medium threat
environment.
In its 2016–17 Portfolio Budget Statements, Defence forecasted a rate of effort of 6227 hours per year Note a:
(2016–17 to 2019–20), but in May 2016, Defence advised the ANAO that it had further revised its future
expectation for rate of effort to 5300 hours. Rate of effort is discussed further in Chapter 3.
Defence has not formally defined the threat levels applicable to the Tiger. In May 2016, Defence indicated that: Note b:
Low threat would indicate a small arms threat only, while medium would indicate the presence of Man
Portable Infra-Red missiles, and a high threat would indicate a coordinated air defence system with
multiple Infra-Red and Radar guided missile systems.
Source: ANAO analysis.
30 The Acquisition Strategy for the Armed Reconnaissance Helicopter capability, provided to the Government in
1998, required two squadrons of Tigers—each squadron with a minimum of six available aircraft (12 aircraft
available in total).
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
28
Figure 2.3: Expected Tiger availability—1 Aviation Regiment (Darwin)
Squadron 161 Squadron 162
Defence’s expected aircraft availability post-Final Operational Capability (8)
Government’s expected aircraft availability at contract signature (12)
Source: ANAO analysis of Defence documents.
In May 2016, Defence advised the ANAO that some of the initial capability descriptions 2.13
were aspirational and its understanding of the requirements for a mature Armed Reconnaissance
Helicopter capability had evolved over the years.
In situations where there are capability shortfalls, the Defence Instruction for accepting 2.14
capability into operational service31 requires Defence to either:
• not accept the capability into operational service and determine a remediation plan; or
• accept the capability shortfall and, in cases where the shortfall ‘places the capability outside
the basis of the Government’s project approval’ Defence must notify and seek agreement
by the Government before the shortfall can be accepted by the Capability Manager.
Defence did not seek Government agreement to these shortfalls prior to declaring Final 2.15
Operational Capability. On 14 April 2016, Defence asked the Minister to note the declaration of Final
31 Department of Defence, DI(G) OPS 45–2, Capability Acceptance into Operational Service, November 2012,
paragraph 14.
Status of the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
29
Operational Capability, but did not make the shortfalls clear in that advice or provide an explanation
of key concepts such as ‘caveats’, ‘non-permissive’32 and ‘medium threat’ environments.
Key deficiencies and limitations—Tiger fleet
In addition to the aircraft’s shortfalls against its initial requirements, Defence has identified 2.16
76 ‘capability deficiencies’ with the Tiger relating to Army’s current and future operational
requirements. Of the 76 deficiencies, 60 (79 per cent) were deemed by Defence to be ‘critical’ and
16 (21 per cent) ‘non-critical’. Defence defines ‘critical’ as deficiencies that need to be resolved as
they unacceptably degrade war fighting capability, limit operational effectiveness, freedom of
navigation and/or aircraft safety. ‘Non-critical’ is defined by Defence as deficiencies that should be
resolved as they inhibit full operational effectiveness and flexibility of the capability.
In addition to these deficiencies, there are other limitations affecting the Tiger fleet. Some 2.17
significant limitations are outlined below.
Shipborne operations
As at May 2016, Tiger was not cleared to operate from any ship. The ability to conduct 2.18
shipborne operations was a requirement specified in the November 1999 Capability Summary33,
and as part of Army’s future operational structure. In 2013, the Army agreed to align the
achievement of Tiger’s shipborne operations capability with the introduction into service of the
Navy’s Landing Helicopter Dock ships. As a result, Defence considered that the achievement of
shipborne operations capability would no longer be a prerequisite for the declaration of Tiger’s
Final Operational Capability, which was restricted to land based operations only. Defence advised
the ANAO that Tiger is currently expected to undertake First of Class Flight Trials34 for shipborne
operations from the Navy’s two new Landing Helicopter Dock ships in mid-2017.
Pilot flying hours
Defence has been unable to achieve sufficient flying hours for its Tiger pilots. Defence 2.19
requires its Tiger pilots to fly a minimum of 150 hours per year in the Tiger. In addition, Tiger pilots
should also complete a minimum of 30 flight simulated hours per year. Defence informed the
ANAO that for the period July–December 2015, Tiger pilots averaged 59.2 flying hours.
Army has also experienced difficulty in maintaining a sufficient cohort of pilots in recent 2.20
years. In June 2014, Defence reported that none of the 99 trained pilots (since 2006) had returned
to 1 Aviation Regiment, Darwin after being rotated to other units. In December 2014, Defence
identified trained pilots and qualified flying instructors as ‘key personnel deficiencies’ for the Tiger
32 Defence’s Land Warfare Doctrine 9-4 defines a permissive environment as ‘Local authorities, forces and the
population are unlikely to oppose or are willing to support Australian Defence Force operations.’ Defence
informed the ANAO that ‘a non-permissive environment [is] where either the local authorities are likely to
oppose [Australian Defence Force] forces directly, or do not control the situation sufficiently to prevent other
forces from acting against the [Australian Defence Force].’
33 The Capability Summary sets out Defence’s initial requirements for the Armed Reconnaissance Helicopter
capability.
34 First of Class Flight Trials involve the development of Ship Helicopter Operating Limits, aircraft handling
procedures and embarkation routines, which aim to determine the limitations and procedures for establishing
a safe and operationally effective interface between the Tiger and Defence’s Landing Helicopter Dock ships.
For a wider discussion of helicopter operations from the Landing Helicopter Docks, see ANAO Report No.9
2015–16, Test and Evaluation of Major Defence Equipment Acquisitions, pp. 59–63.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
30
fleet. In July 2016, Defence advised the ANAO that since June 2014 at least two Commanding
Officers and one Qualified Flight Instructor returned to the unit after posting to other units.
Interoperability and communications: the tactical data link
The acquisition strategy for the Armed Reconnaissance Helicopter was to purchase a 2.21
platform with a communication system that could integrate and interoperate with other Defence
platforms and systems. Defence advised that, at contract signature in 2001, Army’s digital
messaging requirements were not defined due to the infancy of Army’s digital communication
platform requirements. Tiger is equipped with the Eurogrid mapping and mission planning system
and a proprietary data link that allows data communication directly between Tiger aircraft and
Ground-Based Mission Equipment.
At present, the Eurogrid system cannot communicate with Army’s Battle Management 2.22
System or other Army Aviation platforms, due to architecture incompatibility. In addition, Army is
unable to communicate key mission data to and from the Tiger platform in real time.35 These
communications issues reduce the effectiveness of the aircraft as a reconnaissance platform. In
January 2014, Defence reported that the Tiger’s satellite communication performance had failed to
achieve desired expectations and was further limiting the operational capability of the platform.
In August 2014, the Minister for Defence approved a combined First and Second Pass 2.23
acquisition of an ‘interim’ tactical data link solution at an estimated acquisition cost of
$11.6 million.36 Defence decided to proceed with an interim solution rather than pursue a fully
functional tactical data link due to: the complexity of the project; timing; and the availability of
funding to implement and certify. The interim solution was intended to inform the requirements of
the Land 9000 Armed Reconnaissance Helicopter Capability Assurance Program, with an upgraded
tactical data link to be considered as an upgrade option within the Capability Assurance Program.37
Tiger Airworthiness
Airworthiness38 Issues Papers are used by Defence to ensure visibility of all significant 2.24
airworthiness issues in an aviation platform. In April 2016, the Tiger fleet had five open Defence
Airworthiness Issues Papers, which the Airworthiness Board stated was a ‘large number’. Plans
were in place to remediate these issues within twelve months. Open Tiger Airworthiness Issues
Papers are listed in Table 2.3.
35 The Tiger’s data communication with Ground-Based Mission Equipment can only occur prior to and after
flying; it is not able to be conducted in real-time when in flight.
36 The proposal had an estimated Net Personnel and Operating Cost of $2.1 million. The approval sought to
modify 21 of the 22 Tiger Armed Reconnaissance Helicopters, with Defence deciding not to modify the
instrumented helicopter.
37 As discussed in Chapter 4 of this audit report, the Defence Integrated Investment Plan released in February
2016 indicated that the Tiger fleet would be replaced from 2025.
38 Under the Through-Life Support contract (discussed further in Chapter 3), Airbus is required to comply with
Defence’s technical airworthiness and maintenance regulations.
Status of the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
31
Table 2.3: Tiger Airworthiness Issues Papers
Issues Paper Status, April 2016
#18E – Tiger
Instrument Flight
Rules Certification
Airworthiness Issues Paper to remain open until solutions have been
assessed for navigation database corruption and Global Positioning System
in-flight failure.
#23D – Flight Over
Water
There are no current technical solutions available to support First of Class
Flight Trials. Airworthiness Issues Paper will remain open pending further
investigation into Flight Over Water operational scenarios.
#31A – Tiger Cockpit
Smoke and Fumes
This Issues Paper is with Army’s Operational Airworthiness Authority for
review. It was noted as a significant airworthiness issue at the last
Airworthiness Board which is being addressed but requires further attention.
Airworthiness Issues Paper remains open.
#32A – Upper Mode
Automatic Flight
Control System
Disengagement
Airworthiness Issues Paper remains open pending further investigation into
treatments for ‘Upper Mode Automatic Flight Control System’ (auto-pilot)
disengagement.
#34 V1.1 – Aircraft
Structural Integrity
Remediation
The Technical Airworthiness Authoritya endorsed the remediation actions to
address this Issues Paper in September 2015. It was noted as a significant
airworthiness issue at the last Airworthiness Board which is being addressed
but requires further attention. Airworthiness Issues Paper remains open.
The Director General Technical Airworthiness within the Air Force is the Technical Airworthiness Authority for Note a:
all of Defence’s aviation systems.
Source: Department of Defence.
At the October 2015 Airworthiness Board, Defence highlighted that the two major 2.25
Airworthiness concerns are the absence of a Crash Rescue Helicopter in Darwin and staffing
shortfalls. The lack of a suitable crash rescue helicopter or search and rescue capability in Darwin
means that tactical low-flying gunnery activities are restricted except during periods where an
Army Medical Evacuation aircraft is available or during major exercises.
Rocket launchers
One of the weapons available to the Tiger, depending on its configuration, are 70mm 2.26
rocket launchers (either with 19 or seven rockets) that can be mounted on the Tiger’s
multipurpose stub wings. By mounting two of each launcher type, the Tiger can carry up to 52
rockets (see Figure 2.4).
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
32
Figure 2.4: Tiger rocket sub-system
Source: Department of Defence.
Since June 2014, there have been two separate incidents across the world fleet of Tigers 2.27
that have involved the rocket launcher detaching, uncommanded, in mid-flight. One incident
involved a German variant UH Tiger, the other involved an Australian Tiger at Oakey in June 2014.
Defence advised the ANAO that it recovered the rocket launcher from the Oakey incident
however the launcher was damaged beyond repair.
Following the second incident, in September 2014 an Incident Review Meeting considered 2.28
the loss of a rocket launcher pod as a ‘fleet wide risk’. The issue is listed by Defence as a
Noteworthy Hazard. The root cause remains ‘undetermined’. The current mitigation measure,
provided by industry, is to conduct an Intermediate Maintenance on the Tiger Release Unit (which
was not conducted previously). Post-mitigation the risk remains ‘reasonably probable’. Defence
informed the ANAO that ‘the rate of occurrence for this particular incident is very low’ and it has
restricted the Tiger’s operations to ‘not over populated areas’ to reduce risk.
Roof-mounted sight
As discussed, Final Operational Capability for the Tiger fleet was declared for 2.29
environments up to ‘medium threat’. While Defence has not formally defined this term, the
Department advised that ‘medium [threat] would indicate the presence of Man Portable Infra-Red
missiles.’ The original requirement for Tiger’s air-to-ground missile was to provide a guided
weapon accurate out to eight kilometres and outside the range of most Man-Portable Air Defence
Systems.39 While the Tiger’s air-to-ground missile is accurate to these distances, the Tiger’s
roof-mounted sight has an effective range of only around four kilometres. The Tiger may be within
the effective range of enemy fire before the Tiger crew can positively identify and respond to the
threat. In 2015, Defence commented that:
39 Man-Portable Air Defence Systems are lightweight anti-aircraft weapons that are low cost, compact and
mobile.
Status of the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
33
Tiger Roof Mounted Sight (RMS) does not enable the weapon system to achieve range
overmatch in most Australian climatic conditions. [Electronic Warfare Self-Protection] systems
are very good, and will enable operations above terrain flight altitudes in most situations, but the
requirement for positive [identification] of targets will usually mean Tiger weapons release is
within the effective range of [Man-Portable Air Defence Systems].
The approximate range of the roof-mounted sight is illustrated in Figure 2.5 and is 2.30
overlayed with the engagement envelope of a typical Man-Portable Air Defence System and the
effective range of the Tiger’s air-to-ground missile.
Figure 2.5: Roof-mounted sight effective range
Note: Figure not to scale.
Source: ANAO analysis of Defence documents and Department of Foreign Affairs and Trade, Man-Portable Air
Defence Systems (MANPADS), June 2008, p. 5.
Defence advised that this limitation ‘can be overcome by having a ground element lase the 2.31
target, thereby maintaining aircraft stand-off distance.’ Further, Defence informed the ANAO that
‘Tiger has an Electronic Warfare Self Protection System (despite some ongoing issues) that permits
flight inside a [Man-Portable Air Defence System] engagement zone. Standoff range provided by
the Sight and Hellfire are designed to protect against other direct fire weapon systems for which
Tiger has no other defence.’
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
34
3. Sustaining the Tiger Fleet
Areas examined
This Chapter examines Tiger’s through-life support arrangements; sustainment performance
and costs; and Defence’s review of lessons learned from the Tiger sustainment experience.
Conclusion
Shortcomings in the Through-Life Support contract with Airbus limited Defence’s ability to
address sustainment under-performance and the contract was renegotiated twice. Key drivers
of Tiger’s sustainment under-performance include Airbus’s supply-chain constraints, the poor
reliability of Tiger components, and cost. The Tiger has exceeded the operating cost originally
agreed to by Government, and continues to operate at a cost well above Defence’s
expectations. As at June 2016, the cost per flying hour for the Tiger fleet was $30 335,
compared to a target of $20 000. The long-term average was $39 472 per hour.
In 2008 and 2014, Defence sought to address the Tiger’s poor sustainment performance
through renegotiating Deeds to the contract. The 2008 Deed renegotiation did not produce a
satisfactory improvement in sustainment performance—performance since the 2014 contract
amendment has shown signs of improvement with a 29 per cent reduction in operating costs
per flight-hour achieved in the period June 2014–June 2016. Defence’s data shows that, on
average, only 3.5 aircraft—from an operational regiment of 16 aircraft—were considered
serviceable at 10am on any given day in 2015.
Defence’s internal lessons learned review concluded that the ‘rushed’ nature of the initial
Through-Life Support contract negotiations resulted in a flawed outcome for the Tiger Fleet’s
sustainment, and that Defence was ineffective in enforcing its contractual rights under the
Through-Life Support contract. These factors weakened Defence’s position in managing the
Tiger fleet’s sustainment arrangements.
Areas for improvement
The ANAO has recommended that Defence implements arrangements to capture in its policies
and procedures the lessons learned from project reviews of contract and sustainment
arrangements. Key lessons learned should also be disseminated to relevant internal
stakeholders.
Defence’s key arrangement underpinning the sustainment of the Tiger fleet is a Through-3.1
Life Support contract.
Defence’s System Program Offices (which fall within the Capability Acquisition and 3.2
Sustainment Group) are responsible for the administration and oversight of sustainment activities
for specialist military equipment. In the case of the Tiger, Defence has outsourced the majority of
the functions of its System Program Office to Airbus Group Australia Pacific (Airbus). In completing
the roles assigned to it under the Through-Life Support contract, Airbus is supported and overseen
by a small number of Defence uniformed and civilian personnel in the Army Aviation Systems
Program Office of Defence’s Capability Acquisition and Sustainment Group.40
40 The Army Aviation Systems Program Office is responsible for supporting all Army aviation platforms.
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
35
Figure 3.1 illustrates the sustainment arrangements for the Tiger fleet and summarises 3.3
each party’s responsibilities at the time of the audit.
Figure 3.1: Tiger fleet sustainment arrangements and responsibilities
Contract Manager
Army Aviation Systems
Program Office
Operator
Army
Contractor
Airbus
The Army Aviation Systems
Program Office is
responsible, through the
Through-Life Support
contract, for managing the
relationship between Airbus
and Defence. The Office is
also responsible, through
the Design Acceptance
Representative and
engineering staff, for
initiating new and monitoring
existing engineering tasks.
The Office works with Airbus
to provide through-life
support services.
Army is the owner and
operator of the Tiger
capability. Army provides the
funding for the Through-Life
Support contract, and also
conducts operational
maintenance of 1 Aviation
Regiment’s Tigers.
Airbus is the contractor
responsible for delivering
services under the ThroughLife Support contract. Airbus
is responsible for nearly all
support services for the Tiger
fleet, including: deeper
maintenance; operational
maintenance of the training
fleet; the provision of training
support; management of
breakdown spares and
consumables and repairable
items; systems and software
development and testing; and
obsolescence management.
Airbus works with the Army
Aviation Systems Program
Office to deliver these
services, while also providing
distinct engineering support
to the Office.
Provision of funding Payment for through-life support services
Delivery of through-life support services
Engineering supportEngineering support
Defence
Source: ANAO analysis based on information provided by Defence.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
36
Were the through-life support arrangements for the Tiger fleet well
designed to support the achievement of Defence’s sustainment
requirements?
The through-life support arrangements for the Tiger fleet were not well designed. The ThroughLife Support contract signed in 2001 by Defence with Airbus—the single sustainment provider—
provided limited recourse for Defence to address under-performance in Tiger’s required
availability and serviceability. In 2008 and 2014, Defence negotiated changes with Airbus to
improve the Through-Life Support contract. The 2008 contract renegotiation introduced
performance management arrangements, and nearly doubled the value of the sustainment
contract. The 2014 renegotiation further amended the performance management
arrangements, and changed the payment mechanism. Operating costs remain high, and aircraft
availability continues to fall short of target.
The Through-Life Support contract
The Tiger Through-Life Support contract was signed in conjunction with the Acquisition 3.4
contract in 2001, and requires Airbus to sustain the Tiger fleet for a set, in-service period of
15 years, from 1 December 2004 to 30 June 201941, with an option to extend for five years. The
full value of the contract for 15 years of through-life support was $396 million (some $571 million
in inflation adjusted dollars as at June 2016).
The contract established Airbus as a single-source provider for all services required to 3.5
support sustainment of the Tiger, including management and administration, integrated logistics
management services, fleet deeper maintenance services, and training operations and support.
Under the initial contract provisions, Airbus was paid for the value of work done, including the
cost of repairing or replacing parts as required, with the value of these services to be established
annually by Defence and Airbus.42
Defence records indicate that as the Tiger was progressively introduced into service, the 3.6
Australian variant exhibited poor reliability and problems were encountered in manufacturing and
repairing parts as required. In November 2015, a Tiger Airworthiness Board Report observed that:
Ten years of operation has proven that the reliability projections for components under
estimated failure rates, resulting in unscheduled maintenance rates being higher than expected.
The small size of the international fleet43, and Airbus’s reliance on numerous subcontractors 3.7
in Europe44, have also affected Airbus’s ability to sustain the Australian aircraft in an efficient and
timely manner. In response to ongoing under-performance in the sustainment arrangements
(discussed below), Defence has on several occasions written to Airbus’s parent company, Airbus
Helicopters.
41 There was a three-year pre-implementation stage from 2001–02, before the 15 year contract took effect.
42 Under the contract, Airbus was able to claim a ‘Performance Award Fee’ for achieving a result ‘that [was]
better than the contracted performance standard’, and for ‘mak[ing] a material contribution towards the
working relationship between [Airbus] and the Commonwealth’. In March 2016, Defence advised the ANAO
that no Performance Award Fee had been paid.
43 See paragraph 1.2 of this audit report.
44 In 2012, a Defence stocktake identified 28 European subcontractors.
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
37
In 2011, for example, Defence wrote to the Chief Executive Officer of Airbus Helicopters 3.8
expressing concern regarding the cost and sustainment arrangements of the Tiger and Defence’s
other Airbus Helicopters helicopter platform—the MRH90.45 In relation to sustainment
arrangements, Defence highlighted that Airbus Helicopters’ tight control over its sub-contractors
impacted their ability ‘to work directly with the Commonwealth and hence preventing Australian
Defence from achieving value for money by competing work in the market’ and that:
the pace of resolving the technical, reliability and support arrangements has been far too slow.
Australia has attempted to be a pragmatic and positive customer, but we continue to find our
pragmatism brings few favours or positive responses from European industry.
Defence has, on several occasions, raised concerns with and subsequently renegotiated 3.9
the terms of the 2001 Through-Life Support contract with Airbus. Renegotiations occurred in
2007–08 and 2014, focusing, among other things, on aircraft availability.
2007 contract dispute negotiations and the 2008 Deed of Agreement
On 1 June 2007, Defence activated a Stop-Payment provision of its Acquisition contract 3.10
with Airbus, in response to Airbus failing to achieve the Tiger’s contracted Initial Operating
Capability milestone. Defence used this opportunity to address Airbus’s failure to achieve Initial
Operating Capability, and a number of sustainment issues. These included: the pricing of spare
parts; off-aircraft Deeper Maintenance and Repairable Items; payments made to Airbus for
maintenance work that had been undertaken; the price of through-life support for the Ground
Mission Equipment and Electronic Warfare Mission Support System Equipment; transparency of
information provided by Airbus; and the terms of the contract.
On 16 April 2008, Defence and Airbus signed a Deed of Agreement to address the disputed 3.11
issues and improve the performance of the Through-Life Support contract. The Deed introduced a
‘pay for performance’ management arrangement, Key Performance Indicators (including for
availability), and financial penalty provisions for under-performance. In return, Defence agreed to
a revised contract cost of $1054 million46,47 for the provision of eleven years of through-life
support services from 1 July 2008 to 30 June 2019. The Parliamentary Secretary for Defence
Procurement stated:
The Deed of Agreement contains the basis for a Contract Change Proposal that transitions the
current support contract to a performance based structure, to reduce cost of ownership to the
Commonwealth over time. This will help achieve the government’s aim for greater efficiencies in
the sustainment of our major capital equipment.
45 The ANAO reported on the MRH90 in ANAO Report No.52 2013–14, Multi-Role Helicopter Program, June 2014.
46 June 2016 prices.
47 Against an original contract value of $569 million (June 2016 prices) for 15 years of support. At the time the
Deed of Agreement was signed, Defence had paid Airbus $42 million (June 2016 prices) under the ThroughLife Support contract.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
38
The 2008 Deed also amended the liquidated damages clause of the Through-Life Support 3.12
contract. Airbus was required to provide 14 Fully Mission Capable Aircraft daily to 1 Aviation
Regiment, in addition to meeting certain training requirements.48
2011 contract dispute
In June 2011, Airbus entered into a dispute with Defence on the basis that Defence had 3.13
incorrectly calculated Airbus’s performance against the Key Performance Indicator for ‘availability’
introduced as part of the 2008 Deed of Agreement. Airbus claimed that Defence had incorrectly
penalised Airbus for underperformance against the availability indicator. The dispute was over
conflicting interpretations over what constituted an aircraft being classified as ‘available’. The
dispute went to arbitration, and the Arbitrator found in Airbus’s favour. The Arbitrator found that
Defence had applied an incorrect method when calculating Airbus’s performance, stating that:
It may be convenient for those at Darwin to use [the method used by Defence] to determine
Contractor performance but it can only be done by ignoring the plain words of the Contract.
2014 Viability Review Deed
In May 2014, Defence wrote to the President of Airbus Helicopters highlighting that 3.14
‘Australia continues to be dissatisfied with the Tiger in terms of the support arrangements and the
cost of ownership.’ Defence also observed that:
In the not too distant future, Australia will be making a decision as to whether we will upgrade
the Tiger or replace it with [an] alternative platform and your ability to address our concerns
quickly and effectively will be key to the future of the Tiger capability.
Subsequent to this letter, Defence undertook a ‘Strategic Review’ of the Tiger fleet. The 3.15
outcome was to again renegotiate the terms of the Through-Life Support contract. The
negotiation led to a Viability Review Deed, which was implemented in December 2014 and
introduced a number of changes to the Through-Life Support contract, including to the contract’s
payment mechanism and performance management arrangements. The Viability Review Deed
also amended the liquidated damages provision, requiring Airbus, in addition to its training
requirements, to provide an average of 5.25 ‘serviceable’ Tigers per month to 1 Aviation
Regiment, or liquidated damages could be applied. Key Defence engineering staff informed the
ANAO that there was frequent disagreement between Defence and Airbus on the definition of
‘serviceable’, citing differences between French and Australian airworthiness standards.
During the 15 years the Through-Life Support contract has operated, Defence has not 3.16
sought liquidated damages from Airbus. Instead, Defence sought alternate compensation for
under-performance against the Through-Life Support contract, including the provision of additional
supplies and services. Defence advised the ANAO that the additional supplies and services included
an exchange of parts requiring repair for new parts, and additional support, maintenance and
engineering personnel, worth some $4.5 million, at no cost to Defence.
48 The structure of the 2001 Through-Life Support contract provided Defence with limited recourse to seek
compensation or remediation from Airbus for under-performance. Its main accountability mechanism was the
liquidated damages clause, with very limited scope. The clause could be activated if fewer than 16 of 22 Tigers
were ‘allotted’ to 1 Aviation Regiment. The term ‘allotted’ was not defined, and therefore the allotted aircraft
could be in any condition. There were no other penalties incorporated into the contract for underperformance.
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
39
Has Tiger’s sustainment performance met Defence’s requirements?
The Tiger fleet has consistently underperformed against its sustainment metrics and targets for
availability and rate of effort. On average, only 3.5 aircraft, from an operational fleet of
16 aircraft, were considered serviceable at 10am on any given day in 2015.a Further, Defence
considers that the Tiger fleet is unlikely to exceed 74 per cent of its original target for rate of
effort. The revised mature target is 5300 flying hours per year as compared to the original
target of 7147 flying hours.b
The serviceability performance of the training fleet, based at Army’s Aviation Training Centre in Oakey, is Note a:
not considered in this section due to the different requirements applied to the training fleet.
In its 2016–17 Portfolio Budget Statements, Defence forecasted an estimated rate of effort of 6227 hours Note b:
per year (2016–17 to 2019–20).
Performance against the Through-Life Support contract
As discussed, Defence and Airbus agreed in 2008 that the Through-Life Support contract 3.17
would be amended to introduce a number of Key Performance Indicators. The 2014 Viability
Review Deed updated these Indicators. Airbus is required to produce a quarterly performance
report which summarises its performance against five Indicators. Four Indicators49 relate to the
availability of the helicopter fleet and the repair or replacement of parts50:
• Availability:
− Aircraft availability at the operational squadron; and
• Repair and replacement of parts:
− Demand Satisfaction Rate51 – Repairable Items52;
− Demand Satisfaction Rate – Break Down Spares and Consumables53; and
− Timeliness and Quality of Deliverables.54
The contract also sets a ‘Rate of Effort’ target for the Tiger fleet. The rate of effort is the 3.18
total number of hours flown by the Tiger fleet annually.
The following sections report on the available data on the Tiger fleet’s performance 3.19
against the sustainment metrics included in the Though-Life Support contract.
49 The fifth Key Performance Indicator is for Annual Training Program Delivery, and is not considered further in
this audit.
50 These Key Performance Indicators are used to calculate Airbus’s Weighted Performance Score, which in turn
is used to inform the payment of a Quarterly Adjustment Amount.
51 Demand Satisfaction Rate is the number of successfully completed demands (that is, requests) for the supply
or repair of parts compared to the total number of demands.
52 Repairable Items are those items that must be returned to Airbus, and often to the Original Equipment
Manufacturer in Europe, for repair before being returned to the Regiment.
53 Break Down Spares and Consumables are those items that must be replaced once they have reached the end
of their use.
54 This measure was introduced with the signing of the Viability Review Deed, and has been reported since
January 2015.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
40
Availability
Three different metrics have been used over the life of the Through-Life Support contract 3.20
to measure aircraft availability. As a consequence, Defence does not have reliable longitudinal
data covering the full term of the contract. Since January 2015, the Availability Indicator has
measured the percentage of the aircraft55 allocated to Army’s 1 Aviation Regiment that are
determined to be ‘serviceable’ by the Army Aviation Systems Program Office. Under the contract,
an aircraft is serviceable:
• if, at 10am, it is able to be flown on the day of measurement with all such systems
(including applicable Role Equipment) as are necessary to enable the planned mission to
be accomplished being serviceable; or
• if no missions are planned for that aircraft on that day, it is able to be made serviceable
within four hours of 10am (including flight servicing and minor rectification) as
determined by the Commonwealth in its discretion.
Figure 3.2 below shows Airbus’ reported performance against the Availability Key 3.21
Performance Indicator for 2015. The target of 70 per cent was achieved during the first reporting
period, and resulted from an agreement between Airbus and Defence that Airbus be granted a
baseline 100 per cent rating for that quarter. In subsequent reporting periods, performance was
consistently below the target, in a range of 40–55 per cent.
Figure 3.2: Contracted availability performance—January 2015 to December 2015
Source: ANAO analysis of Airbus documents.
55 Two operational squadrons of eight aircraft and an additional aircraft rotated through Deeper Maintenance.
0%
20%
40%
60%
80%
100%
2014–15 Quarter 3 2014–15 Quarter 4 2015–16 Quarter 1 2015–16 Quarter 2
Availability Key Performance Indicator performance
Target (percentage of aircraft allocated to 1 Aviation Regiment)
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
41
As discussed, a component of the availability metric is Defence’s determination of the 3.22
number of aircraft classified as unserviceable that are able to be made serviceable within four hours
of 10am. While some aircraft may be made serviceable during the day, there is no contractual
requirement for this to be achieved, and the metric does not capture performance in this regard.
Achieved serviceability
To establish the rate of achieved aircraft availability—that is the number of aircraft 3.23
determined by Army’s operational regiment’s engineers as able to be flown, with all necessary
systems available, at 10am—the ANAO examined engineering data from Army’s 1 Aviation
Regiment for the calendar year 2015. The ANAO’s analysis shows that 1 Aviation Regiment
engineers have recorded that, on average, only 3.5 of its aircraft were considered to be
serviceable at 10am on any given day.56 On only three occasions were 10 or more serviceable
Tigers available for use by the Regiment.57 The only instance where the fleet met the target of
1258 Tigers classified as serviceable on a single day was on 26 October 2015.
A significant cause of aircraft unavailability was unscheduled maintenance. In June 2015, 3.24
Army reported that ‘unscheduled maintenance was the largest contributor’ to the Tiger’s underperformance in terms of availability. On average, 4.2 of 1 Aviation Regiment’s aircraft were
considered to be unserviceable due to unscheduled maintenance at 10am on any given day. On
3 November 2015, 11 of the Tigers were recorded as unserviceable due to unscheduled
maintenance.
Figure 3.3 below indicates the average number of aircraft recorded as serviceable, per 3.25
month, at 1 Aviation Regiment during 2015.
56 Data used for contractual reporting indicates that, during 2015, Defence determined that an average of
1.9 unserviceable aircraft per day were able to be made serviceable within four hours of 10am. Defence does
not measure the number of aircraft that were made serviceable in this timeframe.
57 The Regiment flew Tigers on 269 days over this period.
58 See paragraph 2.12.
Fi gu re 3
.3
:
A
ve ra ge a irc
ra ft se rv ic ea bi lit
y at 1
0a m , b
y m on th
1
Av ia tio
n R
eg im en t, 20
15
a N
ot e a: Th e R
eg im en t r
ep or ts d ai ly a t 1
0a m o n th e st at us o f e
ac h ai rc ra ft.
T
ho se a irc
ra ft th at a re a bl e to b e us ed a re c la ss ifi
ed a s S
er vi ce ab le . T
he fi gu re s ho w s th e av er ag e nu m be r o
f a
irc
ra ft cl as si fie
d as S
er vi ce ab le –t
ha t i
s, a va ila
bl e an d ab le to fl y th e sp ec ifi
ed m is si on –a
t 1
0a m o n ea ch d ay th at a m ea su re m en t w
as re co rd ed , b
y m on th .
O
n so m e oc ca si on s an a irc
ra ft cl as si fie
d as u ns er vi ce ab le a t 1
0a m m ay b e m ad e se rv ic ea bl e du rin
g th e da y. S
ee p ar ag ra ph s 3.
20
to 3
.2
3.
N
ot e b: Th e G
ov er nm en t a
pp ro ve d ta rg et fo r a
va ila
bi lit
y is 1
2
ai rc ra ft (s ee p ar ag ra ph 2
.1
2)
.
S
ou rc e: A
N
A
O
a na ly si s of D
ep ar tm en t o
f D
ef en ce d at a. 0246810121416 J
an ua ry Fe br ua ry M
ar ch A
pr il M
ay Ju ne Ju ly A
ug us t S
ep te m be r O
ct ob er N
ov em be r D
ec em be r Average number of aircraft serviceable (per month)
S
er vi ce ab le Ta rg et a t G
ov er nm en t a
pp ro va l Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
43
Supply-chain and turn-around of repairable parts
Defence relies on Airbus’s supply-chain to replace or repair parts. Since the arrival of the 3.26
first Tiger in 2004, Defence has experienced delays in accessing parts through the Airbus supplychain, and this was a contributing factor to the two Deed negotiations in 2008 and 2014.
The Through-Life Support contract includes Key Performance Indicators and targets for the 3.27
Tiger fleet’s access to replacement and repaired parts. The ANAO’s review of available data
indicates that between July 2014 and December 2015, Airbus has not always achieved these
targets. For example, Figure 3.4 shows that the Break Down Spare Demand Satisfaction Rate met
the targeted 90 per cent in the first quarter of 2014–15, but did not achieve the target in
subsequent months. The Repairable Item Demand Satisfaction Rate did not achieve the targeted
90 per cent, but came close in the fourth quarter of 2014–15.
Figure 3.4: Demand Satisfaction Rate performance, July 2014–December 2015
Source: ANAO analysis of Airbus documents.
0%
10%
20%
30%
40%
50%
60%
70%
80%
90%
100%
2014–15
Quarter 1
2014–15
Quarter 2
2014–15
Quarter 3
2014–15
Quarter 4
2015–16
Quarter 1
2015–16
Quarter 2
Repairable Item Demand Satisfaction Rate
Break Down Spares Demand Satisfaction Rate
Target
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
44
Rate of effort
Figure 3.5 shows that the Tiger has never achieved the rate of effort targeted under the 3.28
Through-Life Support contract, including an adjusted target rate of effort introduced as part of the
2008 Deed of Agreement.59 In 2015–16, Tiger achieved just over half its rate of effort target. In
Defence’s 2014–15 Financial Statements, the value of the Tiger fleet was impaired by
$101 million—from $705 million to $604 million—due to the unreliability of the Tiger Fleet and its
reduced rate of effort.
Figure 3.5: Tiger rate of effort, 2008–09 to 2015–16
Notes: The contracted rate of effort was adjusted in 2008. Under the original Through-Life Support contract, from
2008–09 onwards the expected rate of effort was presented as a range. The numbers used for this figure are
the lowest of that range for each year.
Source: ANAO analysis of Defence documents.
Defence considers that the Tiger’s rate of effort is likely to improve, but will never reach its 3.29
target. In July 2016, Defence reported internally that:
Tiger will not achieve a mature [rate of effort] of 6227 hours in FY15-16. The actual [rate of
effort] in FY15-16 is forecast to be 4200 hours and the mature [rate of effort] is trending towards
5300 hours.
59 Rate of effort measures total aircraft flying hours, rather than the effectiveness of the Tiger during its flight.
For example, although the Tiger was able to fly, it may not have had any of its mission systems operational, or
may have been restricted in its operation. Defence documents indicate that the Australian Tiger rate of effort
per aircraft (182 hours per aircraft per year in 2015-16) is higher than other international users. Spain
achieves some 122 hours per aircraft per year and Germany achieves some 82 hours per aircraft per year.
0
1000
2000
3000
4000
5000
6000
7000
8000
2008–09 2009–10 2010–11 2011–12 2012–13 2013–14 2014–15 2015–16
H
ou rs Original contracted Rate of Effort Adjusted contracted Rate of Effort
Achieved Rate of Effort
Adjusted
Original
Achieved
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
45
The revised target represents some 74 per cent of the original target rate of effort.60 3.30
Are sustainment costs within budget?
Despite the Tiger fleet’s low rate of effort, by June 2014 sustainment costs for the Tiger had
exceeded the original contract value, with five years still remaining. On a year-to-year basis,
sustainment costs have regularly exceeded Army’s annual allocated budget, in some years by
as much as 20 per cent. Between 2007 and 2016, sustainment costs exceeded Army’s annual
budget by some $54 million. As of July 2016 the cost per flying hour for the Tiger fleet was
$30 335, against a target of $20 000. The long-term average was $39 472 per hour.
In December 2014, Defence and Airbus agreed to new Through-Life Support contract
arrangements that introduced a cap on the growth in the cost of sustainment arrangements.
The maximum total cost of the amended 15 year Through-Life Support contract is $1.32 billion,
more than double the initial contract amount of $571 million (June 2016 out-turned).
The original Through-Life Support contract was valued at $396 million (December 2001 3.31
prices, or $571 million in June 2016 prices). As at June 2016 (12 years into the 15 year contract),
Defence had paid Airbus $921 million for services under the Tiger Through-Life Support contract.61
This was $350 million more than the original contract budget and represented an average cost of
$77 million per year.
Figure 3.6 shows that as the Tiger fleet’s rate of effort increased, the cost to operate the 3.32
fleet increased, peaking at some $130 million in 2013—14, with an average operating cost of some
$39 472 per hour between 2007 and 2016. In 2014, Defence renegotiated the Through-Life Support
contract with Airbus, in part to control escalating sustainment costs (see paragraphs 3.35-3.36).
The amended contract capped Tiger’s sustainment costs, and in the period July 2014–July 2016, the
Tiger’s operating costs per flight-hour had reduced by 29 per cent.
60 In its 2016–17 Portfolio Budget Statements, Defence forecasted an estimated rate of effort of 6227 hours per
year (2016–17 to 2019–20).
61 Of this amount, payments totalling $62 million were made to Airbus for services that were not included in the
budgeted cost of the original Tiger Through-Life Sustainment contract. These payments were primarily for
work falling under the ‘Indefinite Quantities’ clause of the Through-Life Sustainment contract, which is work
‘for which no accurate estimates are available and the Commonwealth guarantees no minimum volume of
work.’ All tasks and costs above the contract cost are funded through Army sustainment funds.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
46
Figure 3.6: Rate of effort, sustainment cost and cost per hour of the Tiger fleet,
2007–08 to 2015–16
Source: ANAO analysis of Defence data.
Defence records indicate that ongoing reliability problems are amongst the key issues for 3.33
the Tiger fleet.62 These problems have been a key driver in the continued high cost of operating
the Tiger and lower than expected rates of serviceability. In May 2014, the Chief Executive Officer
of the Defence Materiel Organisation wrote to the President and Chief Executive Officer of Airbus
Helicopters raising concerns over the high per hour cost of the Tiger aircraft:
This Australian financial year, support to Tiger will cost the Australian tax payer $124 million (not
including operational costs such as fuel and personnel). For this very considerable sum, Tiger will
fly less than 3000 hours. Broadly, this equates to $41,000 per Tiger flying hour. A similar
calculation for our Black Hawk fleet derives a figure of just over $10,000 per hour.
The high cost of operating the Tiger has contributed to Defence regularly exceeding its 3.34
annual internal budget for the fleet, on some occasions by as much as 20 per cent. Figure 3.7 shows
62 In a September 2011 letter to the Minister for Defence, the Chief Executive Officer of the Defence Materiel
Organisation commented that ‘[t]he late realisation of the Tiger capability, largely caused by poor contractor
performance in resolving the many technical, reliability and supportability issues encountered in this program,
is directly limiting military response options available to Government.’
$35,367 $46,337 $46,024 $37,916 $43,788 $37,801 $43,026 $34,652 $30,335
0
500
1000
1500
2000
2500
3000
3500
4000
4500
0
20
40
60
80
100
120
140
20
07
–0
8
20
08
–0
9
20
09
–1
0
20
10
–1
1
20
11
–1
2
20
12
–1
3
20
13
–1
4
20
14
–1
5
20
15
–1
6
R
ate of effort
$
m ill
io ns Achieved rate of effort Sustainment expenditure Cost per hour
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
47
that between 2007 and 2016, then year sustainment expenses ($862 million) have exceeded the
budget ($808 million) by some $54 million, an average overspend of some $6 million per annum.
Figure 3.7: Sustainment cost of the Tiger fleet—annual budget versus actual
An estimate for the cost of sustaining the Tiger was not provided in Defence’s Portfolio Budget Statement Note a:
prior to 2009–10. From 2011–12 to 2014–15, the budget provided in the Materiel Sustainment Agreement
and the estimate provided in the Portfolio Budget Statement were aligned. The budget and estimate differed
in the 2015–16 Portfolio Budget Statement.
Source: ANAO analysis of Defence documents.
By 2013–14, the annual sustainment cost for the Tiger fleet was over $120 million per year, 3.35
and Defence recognised that the cost was likely to continue to increase as rate of effort increased.
In light of this risk, Defence and Airbus agreed in 2014 that the annual cost to the Commonwealth
to support the Tiger fleet was ‘not affordable for the Commonwealth, and, as a consequence, must
be reduced if the [Tiger] Fleet is to be retained in service beyond 30 June 2019’.
In May 2014, the Chief Executive Officer of the Defence Materiel Organisation wrote to 3.36
Airbus setting out an objective of reducing the cost of per aircraft flying hour to $20 000 by 2017–
18. In March 2015, Defence’s Head Helicopters, Tactical Unmanned Aerial Systems and Guided
Weapons Division advised the Minister for Defence that achievement of this cost target had been
brought forward to 2015–16. As at June 2016, Tiger’s cost per flying hour was $30 335.
-
20
40
60
80
100
120
140
2007–08 2008–09 2009–10 2010–11 2011–12 2012–13 2013–14 2014–15 2015–16
$
m ill
io ns Tiger Sustainment actual spend
Tiger Sustainment budget - Materiel Sustainment Agreement
Tiger Sustainment budget - Portfolio Budget Statement estimate
Actual
Portfolio
Budget
Statment
Materiel
Sustainment
Agreement
a ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
48
Cost-cap and future sustainment costs
The 2014 Viability Review Deed amended the 15 year Through-Life Support contract. The 3.37
maximum total cost of the contract is now $1.32 billion63, more than double the initial contract
amount of $571 million (out-turned June 2016 price). The contract ends on 30 June 2019. The
revised contract introduced a cost-cap comprising fixed and variable payments. For the remaining
contract period (2016–17 to 2018–19), a maximum of $402 million (GST exclusive) is available for
sustainment, and payments are linked to the achievement of annual rate of effort targets.
Under the amended contract, Commonwealth payments for the first 84 per cent of the 3.38
Tiger’s rate of effort (5231 hours)64 are higher than payments for the remaining 16 per cent
(996 hours). Payments for this remaining 16 percent are approximately 50 per cent lower per
hour. Defence informed the ANAO that this split is due to the relative risk in achieving the first
80 per cent of the annual rate of effort target, and that the payment model was ‘an effective
means of apportioning risk for both parties in the generation of flying rate of effort.’
Has Defence identified key lessons from the Tiger through-life support
arrangements?
Defence developed a Lessons Learned Report on the Tiger acquisition in April 2015. The Report
highlighted the ‘rushed’ nature of the initial Through-Life Support contract negotiations, which
resulted in a flawed outcome for the Tiger Fleet’s sustainment. The Report also identified that
Defence’s ineffectiveness in enforcing its contractual rights under the Through-Life Support
contract weakened its position in managing the Tiger fleet’s sustainment arrangements.
The Lessons Learned Report made five recommendations. The findings of the report and its
recommendations should be communicated to all current and future sustainment managers
within Defence.
In April 2015, Defence prepared a Lessons Learned Report on the Tiger acquisition which 3.39
was endorsed by the Director General Army Aviation Systems and the Commander of the
Reconnaissance and Air Mobility System Program Office.65 The Report highlighted the
consequences of a ‘rushed’ negotiation on the Through-Life Support contract in order to sign the
contract in conjunction with the Acquisition contract:
If the Through-Life Support contract signature had been delayed the [Tiger] Through-Life Support
contract could have been better scoped and understood by both parties. Problems which may
have been resolved include: Intellectual Property (Commonwealth does not have sufficient
Intellectual Property Rights to compete [Tiger] work to other companies), spares availability and
assessment, subcontractor arrangements, repairable items pipeline performance, [Airbus’s]
ability to undertake work, implementation timeframe etc.
63 Plus an additional, unknown amount, for work falling under the ‘Indefinite Quantities’ clause of the
Through-Life Sustainment contract—see footnote 61.
64 As discussed in paragraph 3.29, Defence has acknowledged that the Tiger’s mature rate of effort is unlikely to
exceed 5300 hours per year. On that basis, most payments will be at the higher rate.
65 In May 2016, Defence advised that the Report was prepared as an annex to the Armed Reconnaissance
Helicopter ‘Project Closure Report’, which is yet to be finalised.
Sustaining the Tiger Fleet
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
49
The report also reflected on Defence’s management of the through-life support 3.40
arrangements with Airbus:
The Commonwealth did not adequately enforce the provisions of the Through-Life Support
contract and if it had, then some of the dispute around sustainment performance may have been
avoided. Inadequate contract management staffing levels, a lack of Commonwealth commercial
acumen and poor leadership all contributed to a weakening of the Commonwealth’s position.
… The Commonwealth needs to rigorously enforce the provisions of its contracts and not give in
to contractor expectations. The Commonwealth needs to hold a hard line in order to shape
contractor behaviour. Continued concession making on the behalf of the Commonwealth will
ultimately lead to contract failure and stakeholder discontent.
The Lessons Learned Report made five recommendations, all focussed on sustainment.66 3.41
Of note, the Report identified that there had been a lack of communication within Defence about
the Tiger fleet’s sustainment issues at the time that the Department was negotiating the ThroughLife Support contract for the MRH90 helicopter fleet, also an Airbus Helicopters product. Defence
identified that this contributed to ‘flawed’ sustainment arrangements for the MRH90 fleet.67
The findings and recommendations of the Lessons Learned Report contain valuable 3.42
insights for Defence on the design and management of its contracting and sustainment
arrangements. There was no evidence that these lessons were communicated outside of the Army
Aviation Systems Program Office to current sustainment managers of other Defence platforms, or
were available to future sustainment managers within Defence. There remains scope for Defence
to communicate lessons learned—often painfully—to relevant internal stakeholders.
Recommendation No.1
That Defence implements arrangements to capture in its policies and procedures the 3.43
lessons learned from project reviews of contract and sustainment arrangements. Key lessons
learned should also be disseminated to relevant internal stakeholders.
Defence’s response: Agreed.
Lessons from the Tiger acquisition project and sustainment are continuously applied to 3.44
deliver capability.
The ANAO’s future Audit Work Program will include an ongoing focus on Defence’s 3.45
sustainment arrangements.
66 The recommendations are listed in Appendix 3 of this audit report.
67 The ANAO examined the MRH90 acquisition in ANAO Report No.52 2013–14, Multi-Role Helicopter Program.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
50
4. Future of the Armed Reconnaissance
Helicopter capability
Areas examined
This Chapter examines Defence’s plans to achieve and maintain the Armed Reconnaissance
Helicopter’s defined capability.
Conclusion
The Tiger platform is based on 1980s–1990s technology and is experiencing an increased level
of obsolescence in its major systems. A number of known obsolescence issues do not have
identified solutions.
Defence has commenced planning for the potential upgrade or replacement of the Tiger fleet
through Project Land 9000 Armed Reconnaissance Helicopter Capability Assurance Program,
which will be considered for Gate Zeroa approval in 2017. The Government has recently
indicated that the Tiger will receive an upgrade at a cost of $500–$750 million, with a
replacement platform to be introduced mid next decade at a cost of $5–$6 billion. In effect, an
upgrade is scheduled for consideration less than 12 months after the Tiger achieved Final
Operational Capability.
Areas for improvement
In considering the future of the Armed Reconnaissance Helicopter capability, the ANAO has
recommended that Defence assesses, and advises Government, on the value-for-money in
investing further in the Tiger aircraft fleet for only a short period of improved performance,
against other alternatives. This assessment should take into account the associated technical
risks of upgrading an aircraft which has not fully delivered Defence’s expected level of
capability.
Gate Zero is the first major approval point for a Defence project, and involves endorsement to establish an Note a:
Integrated Project Team and proceed to the next Gate. Key outputs from Gate Zero are the Business
Case, which is an agreed statement of what Defence assesses it needs to acquire; and the Project
Directive which sets expectations around the resources, timeframes, key issues and risks to be addressed
in order to reach the next Gate.
This Chapter reviews Defence’s planning to date for the future of the Tiger and the Armed 4.1
Reconnaissance Helicopter capability.
Are plans in place to achieve and maintain the defined capability?
The Tiger has a number of systems which are obsolete or are approaching obsolescence.
Defence’s main program for addressing the future of the Tiger is Project Land 9000 Armed
Reconnaissance Helicopter Capability Assurance Program. This Project was initiated in 2014,
and has not yet received Gate Zero approval. The final form of the Capability Assurance
Program—whether to upgrade or replace the Tiger—has not been finalised. Given the current
state of the aircraft, an upgrade of the Tiger would also have to remediate the aircraft’s known
deficiencies.
Future of the Armed Reconnaissance Helicopter capability
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
51
Obsolescence
Defence views obsolescence as ‘the process of becoming out-of-date, superseded or 4.2
unsupportable’. Obsolescence affects ‘all equipment, software, tools, processes, technical data and
other support elements.’ The impact of obsolescence ‘can be costly, both in monetary terms to
rectify the obsolescence problems and in capability terms due to the reduction in required
performance or availability.’ Defence therefore requires that appropriate ‘obsolescence
management activities must be undertaken.’
In 2012, Defence reported internally that: 4.3
AusAero [Australian Aerospace - now Airbus] has not been effectively managing obsolescence for
the [Tiger] program. A number of obsolescence cases have been presented to European
customers years before the [Commonwealth] has been notified by [Airbus]. Current
obsolescence cases which the [Commonwealth] believes are applicable to the [Tiger] are likely to
be expensive to address as there are no longer a range of options available to treat each case.
This is a direct result of time elapsed between announcement of the obsolescence by the
[Original Equipment Manufacturer] to formal [Commonwealth] notification.
The significant scope of obsolescence treatment required for the Tiger is well known to 4.4
Defence, with a 2013 report on a future Tiger capability upgrade program documenting that:
[Tiger] has 148 instances of obsolescence: many substantial … Some items are sustainable in the
short term … [however] there are many instances where the development timeframe for
replacement is unknown, raising the potential for capability gaps if replacements are not
available when spares are exhausted.
In 2014, the number of instances of obsolescence identified by Airbus Helicopters had 4.5
increased to 217, though only 124 were open. At the time of this audit, Airbus Helicopters
reported to Defence that there were some 282 instances of obsolescence, with 149 still open, 12
of which were considered major. In October 2013, Airbus Helicopters wrote to all four Tiger user
nations, noting that the number of obsolescence issues was likely to continue to grow:
[there was] a low rate of increase in the number of obsolescence cases between 2001 and 2005,
however there has been a doubling over the subsequent 4 years (2006 to 2009) and again a further
doubling over the following 3 years (2010 to 2012), with a new peak in 2013 showing a further
doubling of obsolescence cases. This trend is expected to be reinforced beyond 2013 and the
following years, as could be expected with equipment that [has] been developed in the [19]90’s.
A number of the known obsolescence issues do not have identified solutions. In February 4.6
2015, Defence identified that obsolescence is affecting a number of key systems:
Since acquisition of [Tiger], the [Australian Defence Force] has implemented major command
and control, network and information transfer technologies that are not available to Tiger in its
current configuration and are restricting its full employment. Threat weapons system lethality
and proliferation has increased, and tightening of own force rules of engagement requires
increased capacity to achieve Positive Identification of targets from extended range …
In 2014, Airbus provided a financial forecast of known and likely obsolescence issues that 4.7
would require remediation out to June 2023. This forecast estimated that treatment of
obsolescence would cost some $140 million. Airbus is responsible for the cost of treating
obsolescence for the life of the Through-Life Support contract (June 2019). Should Defence elect
to replace an obsolete item with an improved capability—for example, treating the obsolescence
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
52
of the roof-mounted sight by replacing it with a new and improved one—Defence would be
responsible for that cost. In 2013, while evaluating options for a future capability upgrade program,
Defence identified a requirement for significant obsolescence treatment to be undertaken as part of
any upgrade:
Treating obsolescence is an expected component of any mid-life upgrade. For [Tiger], however,
the levels identified to date suggests a more than palatable portion of the allocated budget may
be diverted to address this issue.
Land 9000 Armed Reconnaissance Helicopter Capability Assurance Program
In January 2014, Defence established Project Land 9000 Armed Reconnaissance Helicopter 4.8
Capability Assurance Program. This Capability Assurance Program aims to address technology
obsolescence, and improve the capability and availability of the Armed Reconnaissance Helicopter
through two possible options:
• upgrading the existing Tiger fleet; or
• acquiring a new Armed Reconnaissance Helicopter platform.
As discussed in Chapter 2, the February 2015 Capability Needs Statement for Land 9000 4.9
identified 76 capability deficiencies with the Tiger relating to Army’s current and future operational
requirements that needed to be addressed as part of the Capability Assurance Program. The
Statement observed that ‘elements of [Tiger] obsolescence are already too significant for
treatment through sustainment’, and would need to be addressed by any upgrade program.
Defence informed the ANAO that Gate Zero approval for the Capability Assurance Program 4.10
is scheduled for early 2017. This will closely follow the declaration of Final Operational Capability
in April 2016, placing the Tiger in the position of requiring an upgrade less than 12 months after its
introduction into service.
Tiger System Growth Plan
As part of the Through-Life Support contract, Airbus is required to develop and maintain a 4.11
‘Growth Plan’ for the Tiger fleet. The purpose of the Growth Plan is to:
inform the Commonwealth about candidate technologies for upgrading the [Tiger] … The
expectation is that the Commonwealth will advise industry of its preferred enhancements to
allow investigation that is more detailed and potential grouping of upgrades into modification
packages.
The current Growth Plan was released in October 2015, and encompasses the obsolescence 4.12
issues identified earlier in this Chapter, and the upgrade options available to Defence. Significantly,
the Growth Plan highlights the interdependencies of the Tiger upgrade options—as Defence
upgrades one system, dependent or related systems will also need to be upgraded.
Future of the Armed Reconnaissance Helicopter capability
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
53
Other options
In January 2013, Defence’s Rapid Prototyping, Development and Evaluation unit released a 4.13
report identifying and examining available options for the Tiger’s mid-life upgrade. This report
observed that upgrading the Tiger was a ‘high risk activity’, and noted that consideration should
be given to alternate platform options for delivering the capability for which the Tiger was
originally acquired. In a section titled ‘The Unspoken Option: Replacing the ARH’, the report
suggested that Boeing’s Apache platform was one option:
The pricing for [the Apache] (upfront and in sustainment), alongside the capability difference and
greater certainty about delivery is attractive and warrants strong consideration as an alternate to
upgrading [Tiger]. In fact, a suitably directed business case may establish it is more cost effective
to replace [Tiger] earlier than the planned date.
The report went on to recommend that: 4.14
Alternate platform options should be considered. One option is the [Apache], although it is
acknowledged that there may be other cost competitive platforms. If the accuracy of preliminary
cost estimates for the [Apache] is an impediment to its viability as an alternate, Defence could
pursue Government to Government enquiry to establish the integrity of the figures.
In October 2013, the Defence Materiel Organisation responded to a request from the 4.15
Minister for Defence for an assessment of costs between the Tiger and Apache helicopters. The
report noted that: no in-depth analysis of the costs of acquiring the Apache had been undertaken
since the initial tender process for AIR 87 Phase 2 in 2001; the figures identified in the 2013 report
were ‘not considered reliable’; and that further analysis would be undertaken to develop options
in the lead up to Gate Zero for the Tiger mid-life upgrade.
Defence’s current plans for Tiger
The Government’s Defence Integrated Investment Plan, which was released on 25 February 4.16
2016 alongside the Defence White Paper, acknowledges that:
The Tiger has had a troubled history – essential upgrades are programmed to maintain the
capability’s effectiveness.
Starting in 2017, Defence plans to spend some $500–$750 million remediating and 4.17
upgrading the Tiger, at this stage through Project Land 9000 Armed Reconnaissance Helicopter
Capability Assurance Program. The Investment Plan also commits some $5–$6 billion to replacing
the Tiger:
Defence will invest in a future armed reconnaissance capability to replace Tiger, which could
include manned or unmanned systems or a combination of both, to be introduced from the
mid-2020s.
Tiger Mark 3 Architecture Study
Prior to the release of the Defence Integrated Investment Plan, Defence had committed to 4.18
an Architecture Study for the development of the Tiger Mark 3 variant to potentially replace the
current Tiger fleet. With the release of the Integrated Investment Plan, which identified options
other than Tiger to address Defence’s future capability requirements, Defence paused its
involvement in the Architecture Study.
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
54
Australia’s financial contribution to the Tiger Mark 3 Architecture Study
In support of a potential upgrade of part or all of their Tiger fleets to meet operational
requirements beyond 2020, France, Germany and Australia agreed in 2012 to undertake an
‘Architecture Study’ for a future Tiger Mark 3.a Australia withdrew from the Study in February
2014 and reapplied to participate in November 2014. An internal Defence brief explained
Defence’s involvement in the Study as ensuring that the Commonwealth is operating as a
‘smart buyer’ that achieves value for money.
Following consultation with Airbus Group Australia Pacific (Airbus), in June 2015 Defence paid
Airbus €1 500 000 for Australia’s participation in the Study. In its correspondence, Defence
documented that Airbus’s role in the transaction was to facilitate the movement of these funds
from Defence to Airbus’s European parent company, Airbus Helicopters. These funds were
drawn from the sustainment budget for the Tiger helicopter, although the payment was not
made under the Through-Life Support contract and the Study relates to a future capability.
On 29 February 2016, following the release of the 2016 Defence White Paperb—which
indicated that Australia would look to replace the Tiger helicopter in the mid-2020’s—
Defence advised France, Germany and Spain that:
the immediate impact of this announcement is that [Australia] must pause our involvement in
the Tiger Architecture Study
The commitment of €1 500 000 was approved specifically for Australia’s participation in the
Study, rather than sustainment.c In early July 2016, Defence advised the ANAO that it had
agreed to put the money towards the future sustainment cost of the Tiger.d However,
Defence provided no evidence of a further financial approval for the payment subsequent to
the change in intended purpose for the funds, and could not demonstrate a written
contractual basis for the provision of these monies to Airbus for use against the Through-Life
Support contract. Subsequently (late July 2016), Defence advised the ANAO that:
No financial arrangement nor funds have been transferred to the Architecture Study being
undertaken in Europe as the international legal construct has not been agreed to facilitate this
outcome. Funds have been transferred to Airbus to demonstrate to the other nations that
Australia had a genuine intent to support the Architecture Study when the legal negotiations
conclude. Given the passage of time and lack of progress on agreeing the international
construct for the Architecture Study, arrangements have been made for the funds to be
returned from Airbus to the Commonwealth.
Spain, which is also an operator of the Tiger helicopter, joined the Architecture Study at a later date. Note a:
See paragraphs 4.16 to 4.17. Note b:
The relevant Defence Purchase Order documented that the payment was for ‘Architectural Study – Tiger Note c:
MkIII’. This was consistent with the delegate’s financial approval that the payment was for ‘participation in
the Architecture Study’.
On 27 June 2016, Defence advised the ANAO that ‘no contract was entered into and funds were not Note d:
transferred’ for the purpose of the Study. On 5 July 2016, in response to an ANAO request for clarification
of this advice, Defence acknowledged that a payment had been made to Airbus for the study. Defence
further advised that ’the funding remains held in credit with Airbus Group Australia Pacific for use as Army
may require under the sustainment contract. This funding was not expended on the Architecture Study’.
Future of the Armed Reconnaissance Helicopter capability
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
55
Future Milestones
Figure 4.1 below shows Defence’s proposed future Armed Reconnaissance Helicopter 4.19
capability upgrade and replacement program milestones.
Figure 4.1: Defence’s proposed future Armed Reconnaissance Helicopter capability
upgrade and replacement program—key milestones
2016 2017 2025
2019
Current contract expires
$500-750 million upgrade program
$5-6 billion
replacement program
Source: ANAO analysis of Defence data.
In considering the immediate future of the Armed Reconnaissance Helicopter capability, 4.20
Defence will need to weigh two options:
• invest a further $500–$700 million in the Tiger fleet—which has delivered less than
Defence’s expected capability, and has proven an expensive and unreliable aircraft to
operate—for a short period of improved performance; or
• bring forward an alternative acquisition to address Defence’s Armed Reconnaissance
Helicopter requirements.
The path taken by Defence in addressing the future of the Armed Reconnaissance 4.21
Helicopter capability should be based on the assessed future value-for-money provided to the
Commonwealth, setting aside the sunk cost of previous investments in the Tiger.
Recommendation No.2
That Defence assesses, and advises Government, on the value-for-money in investing 4.22
further in the Tiger aircraft fleet for only a short period of improved performance, against other
alternatives. This assessment should take into account the associated technical risks of
upgrading an aircraft which has not fully delivered the level of capability originally expected by
Government.
Defence’s response: Agreed.
Defence will assess the best value for money and most effective capability for both the 4.23
Tiger Capability Assurance Program and Tiger Replacement. Recommendations on the timings
for both programs will be considered at Gate Zero.
Grant Hehir
Auditor-General
Canberra ACT
1 September 2016
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
57
Appendices
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
59
Appendix 1 Defence’s response to the proposed audit report
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
60
Appendix 2 Airbus Group Australia Pacific’s response to the
proposed report
Appendix 2
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
61
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
62
Appendix 2
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
63
ANAO Report No.11 2016–17
Tiger—Army’s Armed Reconnaissance Helicopter
64
Appendix 3 Recommendations of the ‘Project AIR87 Phase 2—
Rotary Wing for Land Force Project Lessons Learned
Report’
Recommendation 1
The AIR87 [Through-Life Support contract]. needs constant management by experienced 1.
contract management staff with ready access to legal support. The Commonwealth should not be
afraid to challenge the contractor on performance nor enter into contract change discussions with
the contractor should the Commonwealth not receive value-for-money for the contracted
services.
Recommendation 2
The notion that the Commonwealth can optimise resource availability by outsourcing 2.
activities needs to be challenged. This value for money hypothesis is flawed.
Recommendation 3
Better arrangements should be put in place to ensure that appropriate consultations occur 3.
before the Commonwealth enters into similar contracts with the same contractor. AIR9000
[MRH90] did not consult AIR87 to any significant extent before signing the Multi-Role Helicopter
Sustainment Contract and over time this contract has also proven to be flawed.
Recommendation 4
[Defence] needs to re-evaluate its policy in relation to the use of 'cost-plus' contracts. A 4.
cost-plus contract for the initial years of the AIR87 [Through-Life Support contract] would have
ensured effective performance parameters could be set for the mature-state stage of the
contract.
Recommendation 5
The Commonwealth must seek adequate evidence from the Contractor that its 5.
sustainment arrangements with its suppliers/subcontractors are in place and effective and that
any provisions contained in the head contract have been adequately flowed down into any
subcontracts. Demonstration should be linked to sustainment contract signature or as an entry
obligation to the achievement of [In Service Date].

PDF Document reader online

This website is focused on providing document in readable format, online without need to install any type of software on your computer. If you are using thin client, or are not allowed to install document reader of particular type, this application may come in hand for you. Simply upload your document, and Docureader.top will transform it into readable format in a few seconds. Why choose Docureader.top?

  1. Unlimited sharing - you can upload document of any size. If we are able to convert it into readable format, you have it here - saved for later or immediate reading
  2. Cross-platform - no compromised when reading your document. We support most of modern browers without the need of installing any of external plugins. If your device can oper a browser - then you can read any document on it
  3. Simple uploading - no need to register. Just enter your email, title of document and select the file, we do the rest. Once the document is ready for you, you will receive automatic email from us.

Previous 10

Next 10